HomeMy WebLinkAboutAgreement - North Coast Engineering Inc-1
AGREEMENT
THIS AGREEMENT is made and entered into in the City of San Luis Obispo on _____________
by and between the CITY OF SAN LUIS OBISPO, a municipal corporation, hereinafter referred to as City,
and NORTH COAST ENGINEERING INC., hereinafter referred to as Consultant.
W I T N E S S E T H
WHEREAS, on 6/19/19, requested proposals for Civil Engineering Design Services per
Specification No. 5009.2019.CE
WHEREAS, pursuant to said request, Consultant submitted a proposal that was accepted by City
for said services.
NOW THEREFORE, in consideration of their mutual promises, obligations and covenants
hereinafter contained, the parties hereto agree as follows:
1. Contract Term for On-Call Service Contracts. The term of this agreement shall be from the date this
Agreement is made and entered, as first written above. S ervices identified in this specification will be
contracted by the City for four years. Actual work may extend beyond the final date.
2. Cost Increases for On-Call Service Contracts and Contract Extension. Labor rates during the
contract term may be increased on an annual basis to reflect projected increases in labor costs and
overhead provided those increases are incorporated into the Consultant’s Proposal, which is
incorporated into this agreement by reference.
The term of the contract may be extended by mutual consent for an additional year. During this
extended period, labor rates may be increased to reflect increased labor rates and overhead provided
the City is notified and those increases are incorporated into the extension.
3. Work Delays. Should the Consultant be obstructed or delayed in the work required to be done
hereunder by changes in the work or by any default, act, or omission of the City, or by strikes, fire,
earthquake, or any other Act of God, or by the inability to obtain materials, equipment, or labor due to
federal government restrictions arising out of defense or war programs, then the time of completion
may, at the City's sole option, be extended for such periods as may be agreed upon by the City and
the Consultant. In the event that there is insufficient time to grant such extensions prior to the
completion date of the contract, the City may, at the time of acceptance of the work, waive liquidated
damages that may have accrued for failure to complete on time, due to any of the above, after hearing
evidence as to the reasons for such delay, and making a finding as to the causes of same.
4. Termination for Cause. If, during the term of the contract, the City determines that the Consultant is
not faithfully abiding by any term or condition contained herein, the City may notify the Consultant in
writing of such defect or failure to perform. This notice must give the Consultant a 10 (ten) calendar
day notice of time thereafter in which to perform said work or cure the deficiency.
If the Consultant has not performed the work or cured the deficiency within the ten days specified in
the notice, such shall constitute a breach of the contract and the City may terminate the contract
immediately by written notice to the Consultant to said effect. Thereafter, neither party shall have any
further duties, obligations, responsibilities, or rights under the contract except, however, any and all
obligations of the Consultant's surety shall remain in full force and effect, and shall not be extinguished,
reduced, or in any manner waived by the termination thereof.
In said event, the Consultant shall be entitled to the reasonable value of its services performed from
the beginning date in which the breach occurs up to the day it received the City's Notice of Termination,
minus any offset from such payment representing the City's damages from such breach. "Reasonable
value" includes fees or charges for goods or services as of the last milestone or task sati sfactorily
delivered or completed by the Consultant as may be set forth in the Agreement payment schedule;
compensation for any other work, services or goods performed or provided by the Consultant shall be
based solely on the City's assessment of the valu e of the work-in-progress in completing the overall
workscope.
The City reserves the right to delay any such payment until completion or confirmed abandonment of
the project, as may be determined in the City's sole discretion, so as to permit a full and c omplete
accounting of costs. In no event, however, shall the Consultant be entitled to receive in excess of the
compensation quoted in its proposal.
5. Termination for Convenience. The City also reserves the right to terminate the contract for
convenience, providing a 30 (thirty) calendar day notice, at any time upon a determination by the
Director that termination of the contract is in the best interest of the City. Upon termination notice from
the City, Consultant must, unless otherwise directed, cease work and follow the City’s directions as to
work in progress and finished goods. For termination of any services pursuant to this Agreement, the
City’s liability will be the lesser of a reasonable price for the services rendered prior to termination.
6. Ability to Perform. The Consultant warrants that it possesses, or has arranged through subcontracts,
all capital and other equipment, labor, materials, and licenses necessary to carry out and complete the
work hereunder in compliance with any and all applicable federal, state, county, city, and special district
laws, ordinances, and regulations.
7. Sub-contract Provisions. No portion of the work pertinent to this contract shall be subcontracted
without written authorization by the City, except that which is expressly identified in the Consultant’s
proposal. Any substitution of sub-consultants must be approved in writing by the City. For any sub-
contract for services in excess of $25,000, the subcontract shall contain all provisions of this agreement.
8. Contract Assignment. The Consultant shall not assign, transfer, convey or otherwise dispose of the
contract, or its right, title or interest, or its power to execute such a contract to any individual or business
entity of any kind without the previous written consent of the City.
9. Inspection. The Consultant shall furnish City with every reasonable opportunity for City to ascertain
that the services of the Consultant are being performed in accordance with the requirements and
intentions of this contract. All work done and all materials furnished, if any, shall be subject to the City's
inspection and approval. The inspection of such work shall not relieve Consultant of any of its
obligations to fulfill its contract requirements.
10. Record Retention and Audit. For the purpose of determining compliance with various laws and
regulations as well as performance of the contract, the Consultant and sub-consultants shall maintain
all books, documents, papers, accounting records and other evidence pertaining to the perfor mance of
the contract, including but not limited to the cost of administering the contract. Materials shall be made
available at their respective offices at all reasonable times during the contract period and for three years
from the date of final payment under the contract. Authorized representatives of the City shall have
the option of inspecting and/or auditing all records. For Federally funded projects, access to records
shall also include authorized representatives of the State and Federal governme nt. Copies shall be
furnished if requested.
11. Conflict of Interest. The Consultant shall disclose any financial, business, or other relationship with
the City that may have an impact upon the outcome of this contract, or any ensuing City construction
project. The Consultant shall also list current clients who may have a financial interest in the outcome
of this contract, or any ensuing City construction project which will follow. The Consultant staff shall
provide a Conflict of Interest Statement where determined necessary by the City.
The Consultant covenants that it presently has no interest, and shall not acquire any interest —direct,
indirect or otherwise—that would conflict in any manner or degree with the performance of the work
hereunder. The Consultant further covenants that, in the performance of this work, no sub -consultant
or person having such an interest shall be employed. The Consultant certifies that no one who has or
will have any financial interest in performing this work is an officer or employee of the City. It is hereby
expressly agreed that, in the performance of the work hereunder, the Consultant shall at all times be
deemed an independent Consultant and not an agent or employee of the City.
12. Rebates, Kickbacks or Other Unlawful Consideration. The Consultant warrants that this contract
was not obtained or secured through rebates, kickbacks or other unlawful consideration, either
promised or paid to any City employee. For breach or violation of the warranty, the City shall have the
right in its discretion; to terminate the contract without liability; to pay only for the value of the work
actually performed; to deduct from the contract price; or otherwise recover the full amount of such
rebate, kickback or other unlawful consideration.
13. Covenant Against Contingent Fees. The Consultant warrants by execution of this contract that no
person or selling agency has been employed, or retained, to solicit or secure this contract upon an
agreement or understanding, for a commission, percentage, brokerage, or contingent fee, excepting
bona fide employees or bona fide established commercial or selling agencies maintained by the
Consultant for the purpose of securing business. For breach or violation of this warranty, the City ha s
the right to annul this contract without liability; pay only for the value of the work actually performed, or
in its discretion, to deduct from the contract price or consideration, or otherwise recover the full amount
of such commission, percentage, brokerage, or contingent fee.
14. Compliance with Laws and Wage Rates. The Consultant shall keep itself fully informed of and shall
observe and comply with all applicable state and federal laws and county and City of San Luis Obispo
ordinances, regulations and adopted codes during its performance of the work. This includes
compliance with prevailing wage rates and their payment in accordance with California Labor Code.
For purposed of this paragraph, “construction” includes work performed during the design and
preconstruction phases of construction, including but not limited to, inspection and land surveying work.
15. Payment of Taxes. The contract prices shall include full compensation for all taxes that the Consultant
is required to pay.
16. Permits, Licenses and Filing Fees. The Consultant shall procure all permits and licenses, pay all
charges and fees, and file all notices as they pertain to the completion of the Consultant’s work. The
City will pay all application fees for permits required for the completion o f the project including building
and regulatory permit application fees. Consultant will provide a 10 day notice for the City to issue a
check.
17. Safety Provisions. The Consultant shall conform to the rules and regulations pertaining to safety
established by OSHA and the California Division of Industrial Safety.
18. Public and Employee Safety. Whenever the Consultant's operations create a condition hazardous
to the public or City employees, it shall, at its expense and without cost to the City, furnish, erect and
maintain such fences, temporary railings, barricades, lights, signs and other devices and take such
other protective measures as are necessary to prevent accidents or damage or injury to the public and
employees.
19. Preservation of City Property. The Consultant shall provide and install suitable safeguards,
approved by the City, to protect City property from injury or damage. If City property is injured or
damaged resulting from the Consultant's operations, it shall be replaced or restored at the Consultant's
expense. The facilities shall be replaced or restored to a condition as good as when the Consultant
began work.
20. Immigration Act of 1986. The Consultant warrants on behalf of itself and all sub-consultants engaged
for the performance of this work that only persons authorized to work in the United States pursuant to
the Immigration Reform and Control Act of 1986 and other applicable laws shall be employed in the
performance of the work hereunder.
21. Consultant Non-Discrimination. In the award of subcontracts or in performance of this work, the
Consultant agrees that it will not engage in, nor permit such sub-consultants as it may employ, to
engage in discrimination in employment of persons on any basis prohibited by State or Federal law.
22. Accuracy of Specifications. The specifications for this project are believed by the City to be accurate
and to contain no affirmative misrepresentation or any concealment of fact. Consultants are cautioned
to undertake an independent analysis of any test results in the specifications, as City does not guaranty
the accuracy of its interpretation of test results contained in the specifications package. In preparing
its proposal, the Consultant and all sub-consultants named in its proposal shall bear sole responsibility
for proposal preparation errors resulting from any misstatements or omissions in the specifications that
could easily have been ascertained by examining either the project site or accurate test data in the
City's possession. Although the effect of ambiguities or defects in the specifications will be as
determined by law, any patent ambiguity or defect shall give rise to a duty of Consultant to inquire prior
to proposal submittal. Failure to so inquire shall ca use any such ambiguity or defect to be construed
against the Consultant. An ambiguity or defect shall be considered patent if it is of such a nature that
the Consultant, assuming reasonable skill, ability and diligence on its part, knew or should have kno wn
of the existence of the ambiguity or defect. Furthermore, failure of the Consultant or sub -consultants
to notify City in writing of specification defects or ambiguities prior to proposal submittal shall waive any
right to assert said defects or ambiguities subsequent to submittal of the proposal.
To the extent that these specifications constitute performance specifications, the City shall not be liable
for costs incurred by the successful Consultant to achieve the project’s objective or standard beyond
the amounts provided therefor in the proposal.
In the event that, after awarding the contract, any dispute arises as a result of any actual or alleged
ambiguity or defect in the specifications, or any other matter whatsoever, Consultant shall immediately
notify the City in writing, and the Consultant and all sub-consultants shall continue to perform,
irrespective of whether or not the ambiguity or defect is major, material, minor or trivial, and irrespective
of whether or not a change order, time extension, or additional compensation has been granted by City.
Failure to provide the hereinbefore described written notice within one (1) working day of Consultant's
becoming aware of the facts giving rise to the dispute shall constitute a waiver of the right to assert the
causative role of the defect or ambiguity in the plans or specifications concerning the dispute.
23. Hold Harmless and Indemnification.
(a) Non-design, non-construction Professional Services: To the fullest extent permitted by
law (including, but not limited to California Civil Code Sections 2782 and 2782.8), Consultant shall
indemnify, defend, and hold harmless the City, and its elected officials, officers, employees,
volunteers, and agents (“City Indemnitees”), from and against any and all causes of action,
claims, liabilities, obligations, judgments, or damages, including reasonable legal counsels’ fees
and costs of litigation (“claims”), arising out of the Consultant’s performance or Consultant’s
failure to perform its obligations under this Agreement or out of the operations conducted by
Consultant, including the City’s active or passive negligence, except for such loss or damage
arising from the sole negligence or willful misconduct of the City. In the event the City
Indemnitees are made a party to any action, lawsuit, or other adversarial proceeding arising from
Consultant’s performance of this Agreement, the Consultant shall provide a defense to the City
Indemnitees or at the City’s option, reimburse the City Indemnitees their costs of defense,
including reasonable legal fees, incurred in defense of such claims.
(b) Non-design, construction Professional Services: To the extent the Scope of Services
involve a “construction contract” as that phrase is used in Civil Code Section 2783, this paragraph
shall apply in place of paragraph A. To the fullest extent permitted by law (including, but not
limited to California Civil Code Sections 2782 and 2782.8), Consultant shall indemnify, defend,
and hold harmless the City, and its elected officials, officers, employees, volunteers, and agents
(“City Indemnitees”), from and against any and all causes of action, claims, liabilities, obligations,
judgments, or damages, including reasonable legal counsels’ fees and costs of litigation
(“claims”), arising out of the Consultant’s performance or Consultant’s failure to perform its
obligations under this Agreement or out of the operations conducted by Consultant, except for
such loss or damage arising from the active negligence, sole negligence or willful misconduct of
the City. In the event the City Indemnitees are made a party to any action, lawsuit, or other
adversarial proceeding arising from Consultant’s performance of this Agreement, the Consultant
shall provide a defense to the City Indemnitees or at the City’s option, reimburse the City
Indemnitees their costs of defense, including reasonable legal fees, incurred in defense of such
claims.
(c) Design Professional Services: In the event Consultant is a “design professional”, and the
Scope of Services require Consultant to provide “design professional services” as those phrases
are used in Civil Code Section 2782.8, this paragraph shall apply in place of paragraphs A or B.
To the fullest extent permitted by law (including, but not limited to Californ ia Civil Code Sections
2782 and 2782.8) Consultant shall indemnify, defend and hold harmless the City and its elected
officials, officers, employees, volunteers and agents (“City Indemnitees”), from and against all
claims, damages, injuries, losses, and expenses including costs, attorney fees, expert consultant
and expert witness fees arising out of, pertaining to or relating to, the negligence, recklessness or
willful misconduct of Consultant, except to the extent caused by the sole negligence, active
negligence or willful misconduct of the City. Negligence, recklessness or willful misconduct of any
subcontractor employed by Consultant shall be conclusively deemed to be the negligence,
recklessness or willful misconduct of Consultant unless adequately corre cted by Consultant. In
the event the City Indemnitees are made a party to any action, lawsuit, or other adversarial
proceeding arising from Consultant’s performance of this Agreement, the Consultant shall provide
a defense to the City Indemnitees or at the City’s option, reimburse the City Indemnitees their
costs of defense, including reasonable legal fees, incurred in defense of such claims. In no event
shall the cost to defend charged to Consultant under this paragraph exceed Consultant’s
proportionate percentage of fault. However, notwithstanding the previous sentence, in the event
one or more defendants is unable to pay its share of defense costs due to bankruptcy or
dissolution of the business, Consultant shall meet and confer with other parties regard ing unpaid
defense costs.
(d) The review, acceptance or approval of the Consultant’s work or work product by any
indemnified party shall not affect, relieve or reduce the Consultant’s indemnification or defense
obligations. This Section survives completion of the services or the termination of this contract.
The provisions of this Section are not limited by and do not affect the provisions of this contract
relating to insurance.
24. Non-Exclusive Contract. The City reserves the right to contract for the services listed in this proposal
from other consultants during the contract term.
25. Standards. Documents shall conform to City Standards and City furnished templates shall be used.
26. Consultant Endorsement. Technical reports, plans and specifications shall be stamped and signed
by the Consultant where required.
27. Required Deliverable Products and Revisions. The Consultant will be required to provide
documents addressing all elements of the workscope. Plans shall be prepared using City’s
standardized title blocks and coversheets. Draft plans may be submitted for review using either the full
D (24x36) format or a reduced 11x17 format. Consultant shall ensure that drawings and notes are
clearly legible if using the reduced format. Specifications and bid documents shall conform to standard
City formats unless authorized. The City’s current Standard Specifications and Engineering Standards
must be incorporated where applicable.
City staff will review any documents or materials provided by the Consultant and, where necessary, the
Consultant will respond to staff comments and make such changes as deemed appropriate. Submittals
shall include the previous marked up submittal (returned to the Consultant) to assist in the second
review. Changes shall be made as requested or a notation made as to why the change is not
appropriate.
2 copies of the draft preliminary reports, technical studies and 50% plans and estimate
1 copy of the final preliminary reports, technical studies plus markups
3 copies of the 90% plans, specifications and estimate plus 50% markups
1 copy of the 100% plans, specifications and estimate plus 90% markups
1 copy of the final plans, specifications and estimates plus 100% markups
1 copy of the final record drawings after construction
Draft reports and plan submittals shall be submitted as paper copies.
Final documents shall be submitted as camera-ready original, unbound, each page printed on only one
side, including any original graphics in place and scaled to size, ready f or reproduction AND one
electronic copy submitted in Adobe Acrobat format including all original stamps and signatures
In the event the City will be compiling the final specifications, incorporating the Consultant’s work, the
final specifications will also be required to be submitted in Microsoft Word format.
In the event the City will be completing the Record Drawings, the final plans will also be required to be
submitted in AutoCAD
Electronic files shall be submitted on CD and all files must be compati ble with the Microsoft operating
system. Each CD must be clearly labeled and have a printed copy of the directory. Files may be
emailed to the City in lieu of putting them on CD.
28. Ownership of Materials. Upon completion of all work under this contract, ownership and title to all
reports, documents, plans, specifications, and estimates produced as part of this contract will
automatically be vested in the city and no further agreement will be necessary to transfer ownership to
the City. The Consultant shall furnish the City all necessary copies of data needed to complete the
review and approval process.
It is understood and agreed that all calculations, drawings and specifications, whether in hard copy or
machine readable form, are intended for one-time use in the construction of the project for which this
contract has been entered into.
The Consultant is not liable for claims, liabilities, or losses arising out of, or connected with the
modification, or misuse by the City of the machine-readable information and data provided by the
Consultant under this agreement. Further, the Consultant is not liable for claims, liabilities, or losses
arising out of, or connected with any use by City of the project documentation on other projects, except
such use as may be authorized in writing by the Consultant.
29. Release of Reports and Information. Any reports, information, data, or other material given to,
prepared by or assembled by the Consultant as part of the work or services under these specifications
shall be the property of City and shall not be made available to any individual or organization by the
Consultant without the prior written approval of the City.
The Consultant shall not issue any news release or public relations item of any nature, whats oever,
regarding work performed or to be performed under this contract without prior review of the contents
thereof by the City and receipt of the City’s written permission.
30. Copies of Reports and Information. If the City requests additional copies of reports, drawings,
specifications, or any other material in addition to what the Consultant is required to furnish in limited
quantities as part of the work or services under these specifications, the Consultant shall provide such
additional copies as are requested, and City shall compensate the Consultant for the costs of
duplicating of such copies at the Consultant's direct expense.
31. Attendance at Meetings And Hearings. As part of the workscope and included in the contract price
is attendance by the Consultant at up to 1 public meetings to present and discuss its findings and
recommendations. Consultant shall attend as many "working" meetings with staff as necessary in
performing workscope tasks.
32. Requests for Review. The Consultant shall respond to all requests for submittal review or contractor
RFI’s within two weeks of receipt of the information from the City.
33. Project Proposal Submittal. Upon completion of the project scoping meeting, the Consultant shall
submit a proposed workscope, compensation and schedule within 10 working days. The cost proposal
shall include all costs including miscellaneous direct cost items.
34. Consultant Invoices. The Consultant shall deliver a monthly invoice to the City, itemized by project
work phase or, in the case of on-call contracts, by project title. Invoice must include a breakdown of
hours billed and miscellaneous charges and any sub -consultant invoices, similarly broken down, as
supporting detail.
35. Payment. For providing services as specified in this Agreement, City will pay and Consultant shall
receive therefore compensation in a total sum not to exceed the individual agreed upon project fee.
Should the Consultant’s designs, drawings or specifications contain errors or deficiencies, the
Consultant shall be required to correct them at no increase in cost to the City.
For on-call services, the City will pay and the Consultant shall receive compensation as agreed to on a
project by project basis.
The Consultant shall be reimbursed for hours worked at the hourly rates attached to this agreement.
Hourly rates include direct salary costs, employee benefits, overhead and fee. In addition, the
Consultant shall be reimbursed for direct costs other than salary and vehicle cost that have been
identified and are attached to this agreement. The Consultant’s personnel shall be reimbursed for per
diem expenses at a rate not to exceed that currently authorized for State employees under State
Department of Personnel Administration rules.
36. Payment Terms. The City's payment terms are 30 days from the receipt and approval by the City of
an original invoice and acceptance by the City of the materials, supplies, equipment or services
provided by the Consultant (Net 30).
37. Resolution of Disputes. Any dispute, other than audit, concerning a question of fact arising under
this contract that is not disposed of by agreement shall be decided by a committee consisting of the
City’s Project Manager and the City Director of Public Works, who may consider written or verbal
information submitted by the Consultant. Not later than thirty days after completion of all deliverables
necessary to complete the plans, specifications and estimate, the Consultant may request review by
the City Council of unresolved claims or disputes, other than audit, in accordance with Chapter 1.20
Appeals Procedure of the Municipal Code.
Any dispute concerning a question of fact arising under an audit of this contract that is not disposed of
by agreement, shall be reviewed by the City’s Chief Fiscal Officer. Not later than 30 days after issuance
of the final audit report, the Consultant may request a review by the City’s Chief Fiscal Officer of
unresolved audit issues. The request for review must be submitted in writing.
Neither the pendency of a disput e, nor its consideration by the City will excuse the consultant from full
and timely performance in accordance with the terms of this contract.
38. Disadvantaged Business Enterprise (DBE) Use for Federally Funded Projects. This agreement
is subject to Title 49, Part 26 Code of Federal Regulations entitled “Participation by Disadvantaged
Business Enterprises in Department of Transportation Financial Assistance Programs” when project
work is for a federally funded project. In order to ensure the State Department of Transportation
achieves its federally mandated statewide overall DBE goal, the City encourages the participation of
DBEs as defined in 49 CFR 26 in the performance of this agreement. The City will make a
determination on a project by project basis for reasonably expected DBE participation to compete for
the sub-consulting opportunities in this agreement. The Consultant is responsible to be fully informed
regarding the requirements of 49 CFR, Part 26
The Consultant shall notify the City of any changes to its anticipated DBE participation on federally
funded projects, maintain records of DBE usage and complete and submit to the City the final report of
DBE utilization prior to receiving final payment. Records shall show the name and business address
of each DBE and the total dollar amount actually paid to each.
The Consultant shall pay all sub-consultants within 10 calendar days from receipt of each payment
made to the Consultant by the City.
The Consultant shall carry out applicable require ments of Title 49 CFR 26 in the award and
administration of US DOT assisted agreements. Failure by the Consultant to carry out these
requirements is a material breach of this agreement, which may result in the termination of this
agreement or such other remedy as the City deems appropriate.
39. Agreement Parties.
City: Hai Nguyen
City of San Luis Obispo
919 Palm Street
San Luis Obispo, CA 93401
Consultant: Greg S. Jaeger, PE
North Coast Engineering, Inc.
725 Creston Road. Suite B
Paso Robles, CA 93446
All written notices to the parties hereto shall be sent by United States mail, postage prepaid by
registered or certified mail addressed as shown above.
40. Incorporation by Reference. City Request for Qualifications Specification No. 5009.2019.CE and
Consultant's proposal dated 8/1/2019, are hereby incorporated in and made a part of this Agreement.
Should there be any conflict between terms set forth in the City Request for Qualifications Specification
No. 5009.2019.CE and Consultant’s proposal dated 8/1/2019, the terms in this agreement and City
Request for Qualifications Specification No. 5009.2019.CE will govern.
41. Amendments. Any amendment, modification or variation from the terms of this Agreement shall be
in writing and shall be effective only upon approval by the City Engineer.
42. Working Out of Scope. If, at any time during the project, the consultant is directed to do work by
persons other than the City Project Manager and the Consultant believes that the work is outside of the
scope of the original contract, the Consultant shall inform the Project Man ager immediately. If the
Project Manager and Consultant both agree that the work is outside of the project scope and is
necessary to the successful completion of the project, then a fee will be established for such work
based on Consultant's hourly billing rates or a lump sum price agreed upon between the City and the
Consultant. Any extra work performed by Consultant without prior written approval from the City Project
Manager shall be at Consultant's own expense.
43. Complete Agreement. This written agreement, including all writings specifically incorporated herein
by reference, shall constitute the complete agreement between the parties hereto. No oral agreement,
understanding or representation not reduced to writing and specifically incorporated herein s hall be of
any force or effect, nor shall any such oral agreement, understanding or representation be binding upon
the parties hereto. For and in consideration of the payments and agreements hereinbefore mentioned
to be made and performed by City, Consultant agrees with City to do everything required by this
Agreement, the said specification and incorporated documents.
Authority to Execute Agreement. Both City and Consultant do covenant that each individual executing
this agreement on behalf of each party is a person duly authorized and empowered to execute Agreements
for such party.
IN WITNESS WHEREOF, the parties hereto have caused this instrument to be executed the day and year
first above written.
CITY OF SAN LUIS OBISPO: CONSULTANT:
___________________________________
North Coast Engineering, Inc.
___________________________________
Derek Johnson, City Manager Greg S. Jaeger
Vice President
APPROVED AS TO FORM:
__________________________________
Christine Dietrick, City Attorney
______________________________
John R. Sanders, PLS
President