HomeMy WebLinkAboutR-10930 RFQ for Electrical Subcontractors for WRRF ProjectCITY OF SAN LUIS OBISPO
REQUEST FOR STATEMENTS OF QUALIFICATION
Electrical Subcontractors
FOR CONSTRUCTION OF
THE WATER RESOURCE RECOVERY FACILITY
PROJECT
August 2018
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 4
City of San Luis Obispo i Water Resource Recovery Facility Project
Request for Statements of Qualification
TABLE OF CONTENTS
1. INTRODUCTION ................................................................................................... 1
OBJECTIVE .......................................................................................................... 2
PREQUALIFICATION OUTREACH MEETING ..................................................... 2
PROJECT DESCRIPTION .................................................................................... 2
2. INSTRUCTIONS FOR PREPARATION AND SUBMISSION OF
PREQUALIFICATION PACKAGES ..................................................................... 3
CERTIFICATION ................................................................................................... 4
PUBLIC RECORDS .............................................................................................. 4
TIME AND PLACE FOR SUBMISSION OF CANDIDATE RESPONSES ............. 5
EVALUATION PROCESS ..................................................................................... 6
NOTIFICATION ..................................................................................................... 6
PROTEST PROCEDURE ..................................................................................... 7
APPEALS PROCESS ........................................................................................... 7
3. PROJECT SCHEDULE ........................................................................................ 8
4. TERMS AND CONDITIONS GOVERNING THE RFQ ......................................... 8
COSTS OF RESPONDING; RETENTION BY CITY OF QUESTIONNAIRES AND
RELATED DOCUMENTS ................................................................................ 8
RESERVATION OF RIGHTS BY CITY ................................................................. 9
5. CANDIDATE QUESTIONS, REQUESTS FOR CLARIFICATION, AND
REQUESTS FOR EXCEPTIONS ......................................................................... 9
6. PROJECT ADMINISTRATION ............................................................................. 9
7. ACKNOWLEDGMENT ....................................................................................... 10
APPENDIX A: CANDIDATE CONTACT INFORMATION FORM
APPENDIX B: PREQUALIFICATION QUESTIONNAIRE
APPENDIX C: PROJECT DATA SHEET PERFORMANCE RECORD
APPENDIX D: RELEASE AND WAIVER AGREEMENT
APPENDIX E: PROJECT REFERENCE QUESTIONNAIRE
APPENDIX F: AFFIDAVIT
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 5
City of San Luis Obispo ii Water Resource Recovery Facility Project
Request for Statements of Qualification
TABLE OF CONTENTS (CONTINUED)
APPENDIX G: KEY PERSONNEL DATA SHEET
APPENDIX H: CITY MINIMUM INSURANCE REQUIREMENTS
APPENDIX I: CERTIFICATION OF SURETY
APPENDIX J: SCORING INSTRUCTIONS
APPENDIX K: PREQUALIFICATION EVALUATION
APPENDIX L: REFERENCE DRAWINGS
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 6
City of San Luis Obispo 1 Water Resource Recovery Facility Project
Request for Statements of Qualification
Request for
STATEMENTS OF QUALIFICATION
Electrical Subcontractors for Construction of the
WATER RESOURCE RECOVERY FACILITY PROJECT
1. INTRODUCTION
The City of San Luis Obispo (“City”) is issuing this Request for Statements of Qualification (RFQ)
in search of candidates (“Candidates”) who have the necessary qualifications as set forth in this
RFQ to be prequalified to submit an electrical subcontract bid to prequalified general contractors
on the City’s Water Resource Recovery Facility Project (“Project”).
The City has determined that electrical subcontractors interested in bidding on this Project must
be prequalified prior to submitting a bid (to general contractors). Electrical subcontractors
specifically experienced with large scale municipal wastewater, recycled water, or potable water
treatment plant construction are invited to participate in the prequalification process. Candidates
must fully complete the prequalification application package (“Prequalification Package”),
including but not limited to the Prequalification Questionnaire (“Questionnaire”), provide all
materials requested herein, and be deemed prequalified by City to be eligible to submit bids for
the electrical scope of the Project to prequalified general contractors. The final list of prequalified
general contractors, electrical subcontractors, and control systems integrators will be issued
following evaluation of the Prequalification Packages. The City will not accept a bid proposal from
any general contractor that is not on the Project Bidders List and the City will not accept a bid
from any prequalified general contractor that does not list a prequalified electrical subcontractor
for the electrical portion of the Project scope and a prequalified control systems integrator for the
systems integration portion of the Project scope, or complete the separate prequalification
process for electrical subcontractors and control systems integrators itself and be prequalified to
self-perform that work. If two or more business entities intend to submit a bid as part of a Joint
Venture, each entity within the Joint Venture must submit a fully complete Prequalification
Package and be separately qualified to bid.
The prequalification procedure involves the review and evaluation of information regarding the
proven experience of Candidates to construct the Project in a manner acceptable to the City. The
experience of each Candidate will be evaluated on the basis of the qualification submittal and
information gathered by the City from the references of related projects. Proven experience is
defined as the actual performance of the Candidate on previous construction projects of a similar
size and complexity as corroborated by said references. The City is not obligated to prequalify or
accept a Candidate with no or unsatisfactory related experience.
Candidates may obtain an electronic copy of the Prequalification Package and excerpts from the
preliminary design plans from www.bidsync.com. Responses to Candidates’ questions and any
addenda to the RFQ will be posted to www.bidsync.com. Portions of the 60% preliminary design
submittal are provided for information only and are not intended for bidding or construction
purposes. Prequalified bidders will be responsible to prepare bids based on the final design plans
and contract documents to be issued with the Notice Inviting Bids.
The City reserves the right to cancel this Notice or to reject any and all responses and
Prequalification Packages, if it determines, in its sole discretion, that such cancellation or rejection
is in the best interest of the City. The City reserves the right to bid the Project without use of the
Bidders List.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 7
City of San Luis Obispo 2 Water Resource Recovery Facility Project
Request for Statements of Qualification
Objective
The objective of this RFQ is to provide sufficient information to enable Candidates to submit
written Prequalification Packages. Only qualified Candidates will be eligible to submit a bid to the
general contractor for electrical construction services for the Project. It is required that the
electrical subcontractor perform the majority (i.e., greater than 50%) of the electrical work.
Candidates responding to this RFQ do so with the understanding that they are not guaranteed
the awarding of contracts and work. Qualified Candidates may be required to meet additional
qualifications as detailed in the Project bid package.
In addition to this Prequalification Package for electrical subcontractors, general contractors and
control systems integrators must also be prequalified under a separate, but concurrent,
prequalification process. Should a general contractor plan to self-perform the electrical work or
the control systems integration work, it will need to submit an electrical subcontractor
Prequalification Package and a control systems integrator Prequalification Package. Should a
general contractor be prequalified by the Owner as a general contractor and not an electrical
subcontractor and/or a control systems integrator, that general contractor will not be allowed to
self-perform the electrical work and/or the control systems integration work and must use one of
the electrical subcontractors and control systems integrators that is approved by the City for the
electrical work and control systems integration work. Likewise, should a general contractor be
prequalified as an electrical subcontractor and/or a control systems integrator and not as a
general contractor, that general contractor will not be allowed to submit a bid to the City as a
general contractor. However, that same general contractor can submit a quote for the electrical
work and/or the control systems integration work to any of the general contractors that are
prequalified by the City.
Prequalification Outreach Meeting
A non-mandatory prequalification outreach meeting and site tour has been scheduled for
September 5, 2018, at 10:00 AM. The purpose of the prequalification outreach meeting is to
introduce the Project and the prequalification process. The prequalification meeting will be held
at the City’s Corporation Yard, 25 Prado Road, San Luis Obispo, 93401.
Project Description
The City owns and operates the Water Resource Recovery Facility (“WRRF”) located on Prado
Road in San Luis Obispo, California. The WRRF treats municipal wastewater collected from the
City, California Polytechnic State University (Cal Poly), and the San Luis Obispo County Airport
under Waste Discharge Requirements (WDR) R3-2014-0033 and National Pollutant Discharge
Elimination System (NPDES) No. CA0049224. The WRRF is currently rated for 5.1 million gallons
per day (mgd) of average dry weather flow (ADWF) conditions and currently treats an average of
approximately 3.1 mgd under ADWF conditions. After being treated, the water is either recycled
or discharged to San Luis Obispo Creek.
The WRRF was originally constructed in 1923 and upgraded or expanded in 1942, 1962, 1982,
and 1994, and in 2006 the water reuse facilities were added. The Project will upgrade the WRRF
to meet City’s new NPDES permit, treat future flows and loading, replace aging equipment,
maximize the production of recycled water, and incorporate interpretive features and public
amenities.
A key driver of the Project is the new NPDES permit adopted in September 2014 (effective
December 1, 2014). The new permit includes discharge limitations that will require significant
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 8
City of San Luis Obispo 3 Water Resource Recovery Facility Project
Request for Statements of Qualification
process upgrades. Specifically, the new permit includes strict disinfection byproduct limits which
will require a new disinfection technology, as well as nitrate limits which will require a significant
upgrade of the secondary treatment processes. A new Time Schedule Order (TSO) was also
adopted in September 2014 which requires City to achieve the disinfection byproduct limits and
nitrate limits by November 30, 2019.
Project improvements include the construction of a new Water Resource Center with process
laboratory and educational space; expanded flow equalization basin, flow structure modifications
and new flow equalization pump station; headworks modifications; odor control system; primary
clarifier modifications, new primary sludge pumping system, and new primary scum pumping
system; new chemical facilities; new primary effluent screens; modifications to existing bioreactor
basins; new bioreactor basins and a membrane bioreactor (MBR) facility; new ultraviolet (UV)
disinfection facility; new effluent cooling facility; gravity thickener modifications; new sludge
thickening facility; new aerobic digester, modifications to existing digester, modifications to sludge
storage tank, and modifications to existing digester equipment; site electrical facilities; site work;
and landscaping.
The Project has been conditionally approved to receive funding from the State Water Resources
Control Board through the Clean Water State Revolving Fund (CWSRF). Eligible bidders will be
required to comply with all CWSRF requirements including Disadvantaged Business Enterprise
(DBE) outreach, Federal Davis Bacon wage rates, and utilization of American Iron and Steel.
Preliminary Construction Drawings
Select drawings from the 60% preliminary design submittal have been included as Appendix L.
These drawings are for reference only, are subject to change through the design process and are
not to be used for bidding purposes.
Engineer’s Opinion of Probable Construction Cost
The estimated construction cost of the Project is between $103 million and $132 million. The
estimated cost of the electrical portion of the work is approximately $27 million.
2. INSTRUCTIONS FOR PREPARATION AND SUBMISSION OF PREQUALIFICATION
PACKAGES
Each electrical subcontractor wishing to submit a bid to a prequalified general contractor for
electrical construction services must fully complete the Prequalification Package and provide all
information and materials requested and satisfy the prequalification criteria. If two or more
business entities wish to bid the Project as a joint venture ("JV"), each entity must fully complete
the Prequalification Package and be separately deemed prequalified to bid. The JV must be
properly licensed by the California Contractors State License Board and registered with the
California Department of Industrial Relations before the construction contract is executed.
Answers to questions contained in the Prequalification Package, information about current
bonding capacity, a notarized statement from surety, with accompanying notes and supplemental
information, will be used by the City in order to rate Candidates with respect to their qualifications
to provide electrical construction services on the Project. The City reserves the right to check any
other sources available to verify Candidate’s statements, prior performance and veracity. The
City’s decision will be based on objective evaluation criteria described in the Evaluation Process
Section below.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 9
City of San Luis Obispo 4 Water Resource Recovery Facility Project
Request for Statements of Qualification
While the prequalification process is intended to assist the City in determining bidder responsibility
prior to bid, neither the fact of prequalification, nor any prequalification rating, will preclude the
City from a post-bid consideration and determination of whether a bidder has the quality, fitness,
capacity and experience to satisfactorily perform the proposed work, and has demonstrated the
requisite trustworthiness.
Candidates shall provide only complete and accurate information. The Candidate acknowledges
that the City is relying on the truth and accuracy of the responses contained herein. If any
information provided by a Candidate becomes inaccurate, the Candidate must immediately notify
the City and provide updated accurate information in writing, accompanied by an affidavit made
under penalty of perjury. Should a Candidate omit requested information or falsify information,
the City may determine that the contractor is not qualified.
Attach additional sheets as needed to provide complete responses.
Except where information related to former entities is expressly required, for purposes of
evaluation, scoring and prequalification, all required Candidate information, including but not
limited to experience, personnel and finances, must be provided for the licensed entity that will be
bidding for the contract to construct the Project. Information related to parent companies,
subsidiaries, and any other related entity or proposed subcontractors will not be considered.
The prequalification of contractors will be determined by evaluation of the information submitted
by Candidates. The City may verify any or all information provided in completed Prequalification
Package, consider information provided by sources other than the Candidate, and conduct such
investigations as the City deems appropriate to assist in the evaluation of Candidate's
responsibility, qualifications, and financial capacity.
If a Candidate seeking prequalification has not been in business for the time period for which
information is requested, it shall submit information on predecessor entities covering that time
period.
The City may refuse to grant prequalification where the requested information and materials are
not provided. There is no appeal from the City’s decision not to prequalify a Candidate due to an
incomplete or late application.
Certification
Each Prequalification Package must be completed with all information requested and be signed
under penalty of perjury by an individual who has the legal authority to bind the Candidate seeking
prequalification. The City must receive all Prequalification Packages and materials requested
therein by the date and time stated in This RFQ. Prequalification Packages that are incomplete,
unsigned or received after the specified time may be returned unopened, and the Candidate will
not be eligible to participate in the bidding of the Project.
Public Records
As provided in Public Contract Code Section 20101, the Prequalification Packages submitted by
Candidates are not public records and are not open to public inspection. All information provided
will be kept confidential to the extent permitted by law. However, the contents may be disclosed
to third parties for purpose of verification or investigation, or in an appeal hearing. State law
requires that the names of Candidates applying for prequalification status shall be public records
subject to disclosure, and the first page of the Questionnaire will be used for that purpose.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 10
City of San Luis Obispo 5 Water Resource Recovery Facility Project
Request for Statements of Qualification
Time and Place for Submission of Candidate Responses
The Prequalification Package shall be submitted in person or sent via courier or U.S. mail (other
means of transmission, including facsimile and email, will not be accepted) in a sealed envelope
and clearly marked “CONFIDENTIAL” by 2:00 PM, local prevailing time, on October 9, 2018, as
follows:
“City of San Luis Obispo, Public Works Department
919 Palm Street
San Luis Obispo, CA 93401
Attn: David Hix
CONFIDENTIAL – Statement of Qualifications: Electrical Subcontractors for
Construction of Water Resource Recovery Facility Project”
Candidate shall submit one (1) hard copy original, bound or in a three-ring binder, clearly marked
“CONFIDENTIAL, ORIGINAL” on the outside cover and containing an original “ink” signature. In
addition, the Candidate shall submit one (1) electronic version of the Prequalification Package on
a separate CD ROM, DVD, or solid state “flash” USB drive containing the Prequalification
Package in one searchable PDF file.
Each Candidate shall submit a Prequalification Package, which consists of the following, in one
(1) sealed envelope:
One (1) copy of the completed Acknowledgement (Page 10 of RFQ);
One (1) copy of the completed Candidate Contact Information Form (Appendix A);
One (1) copy of the Prequalification Questionnaire and related information (Appendix B);
One (1) copy of each Project Data Sheet (Appendix C);
One (1) copy of each Release and Waiver Agreement (Appendix D);
One (1) copy of EMR verification letter from insurance carrier (Appendix B, Part II,
Question G.32)
One (1) copy of each Key Personnel Data Sheet (Appendix G);
One (1) copy of the completed Affidavit (Appendix F);
One (1) copy of completed Certification of Surety (Appendix I); and
One (1) CD, DVD, or solid state “flash” USB drive containing a PDF file of the above
documents.
The list of Qualified Candidates will be posted on www.bidsync.com on the date indicated in the
schedule below. Candidates receiving a determination of “Not Qualified” will be notified of their
status.
Prequalification Packages received after the deadline will not be considered. There is no appeal
from a denial due to an incomplete application. The City reserves the right to contact a Candidate
for clarification or further information. The City will not be responsible for submittals that are
delinquent, lost, mismarked, sent to an address other than the address provided above or sent
by mail or courier service and not signed for by the City.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 11
City of San Luis Obispo 6 Water Resource Recovery Facility Project
Request for Statements of Qualification
Evaluation Process
To prequalify, a Candidate must fully complete the Candidate Contact Information Form,
Prequalification Questionnaire, and other information requested within this RFQ. In the case of
joint ventures, a complete Prequalification Package must be submitted individually for each joint
venture partner.
A committee formed by the City will evaluate responses to the RFQ. Members of the evaluation
committee may include some or all of the following: City officials and staff and City’s consultants.
Evaluations of RFQs are subject to the sole discretion of the evaluation committee. Following
completion of the evaluation process, the evaluation committee will forward its determination to
the Candidates. The City reserves the right to rescind any Candidate’s Qualified Candidate status
if it is determined that the facts provided by the Candidate are inaccurate.
Candidates will be evaluated based upon their responses to the Prequalification Questionnaire,
which consists of the following three (3) parts:
Part I, Essential Requirements for Qualification:
All questions are pass/fail. Candidates must pass all of the questions to be qualified to
submit a Bid on the Project.
Part II, Information Regarding the Organization, History, Performance, and
Compliance with Civil and Criminal Laws:
Candidates are required to provide information related to the team composition,
company organization, business history and performance, and licenses.
Candidates are required to answer questions regarding history of financial and
professional responsibility.
Candidates are required to provide information regarding disputes, criminal
matters and related suits, compliance with occupational safety and health laws,
and compliance with labor laws.
Part III, Mandatory Project Experience
Candidates are required to complete a minimum technical qualification
questionnaire and submit Project Data Sheets for the referenced projects.
In addition, for each of the required Project Data Sheets, a Reference
Questionnaire will be sent to the project owners. Candidates must score a
minimum of 122 points out of a possible 175 points on each Reference
Questionnaire to be qualified to proceed with the evaluation process.
Notification
The City will notify each Candidate as to whether it has been prequalified to bid on the Project
through a Notice of Determination. Following issuance of a Notice of Determination, the City
reserves the right to suspend or rescind the Qualified Candidate rating of Candidates based on
subsequently learned information.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 12
City of San Luis Obispo 7 Water Resource Recovery Facility Project
Request for Statements of Qualification
Protest Procedure
A. Any protest relating to the form or content of the RFQ must be submitted in writing at least
ten (10) business days before the original deadline for submitting Statements of Qualification. Any
Candidate who submits a Statement of Qualifications without making a protest shall be deemed
to have waived any objection to the form and content of the RFQ documents and evaluation
process.
B. A Candidate may file a “protest” of the RFQ with the City.
C. Any protest must meet all of the following requirements:
1. Be filed in writing within five (5) business days after the RFQ is first posted or
published;
2. Clearly identify the alleged irregularity or other basis for the protest; and
3. Specify, in detail, the factual and legal grounds for the protest.
D. If the protest does not meet all of these requirements, the City may reject it without further
review.
E. If the protest is timely and complies with all of the above requirements, the City shall review
the protest and all relevant information. The City will provide a written response to the protestor.
F. The procedure and time limits set forth in this paragraph are mandatory and are the sole
and exclusive remedy in the event of a protest. Failure to comply with these procedures shall
constitute a failure to exhaust administrative remedies and a waiver of any right to further pursue
the protest, including filing a Government Code Claim or legal proceedings.
Appeals Process
Where a timely and completed prequalification application results in a rating below that necessary
to prequalify, the Candidate can appeal the determination. To appeal, the Candidate must deliver
notice to the City of its appeal of the decision with respect to its prequalification determination, no
later than five (5) business days after City staff issues its recommendation of the qualified Project
Bidders List. Without a timely notice of appeal, the Candidate waives any and all rights to
challenge the decision of the City, whether by administrative process, judicial process, or any
other legal process or proceeding. The procedure and time limits set forth in this paragraph are
mandatory and are the sole and exclusive remedy in the event a Candidate contests the City’s
decision. Failure to comply with these procedures shall constitute a failure to exhaust
administrative remedies and a waiver of any right to further pursue the bid protest, including filing
a Government Code Claim or legal proceedings.
The letter of appeal must include a written statement specifying in detail each and every one of
the grounds asserted for the appeal. The letter of appeal must be signed by an individual
authorized to represent the Candidate and must cite the relevant section of the RFQ or Appendix
on which the appeal is based. In addition, the Candidate must specify facts and evidence sufficient
for the City to determine the validity of the appeal.
If a letter of appeal is mailed, the Candidate bears the risk of non-delivery within the deadlines
specified herein. Letters of appeal should be transmitted by a means that will conclusively
establish the date the City receives the appeal. Appeals or notice of appeals made orally (e.g., by
telephone) will not be considered. Letters of appeal must be delivered to the Project Manager as
described in Section 6 “Project Administration”.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 13
City of San Luis Obispo 8 Water Resource Recovery Facility Project
Request for Statements of Qualification
If the Candidate files a complete and timely letter of appeal, a review of the appeal shall
commence soon after receipt of the request. The review shall be an informal process conducted
by the City or its designee and will be based upon the information submitted by the Candidate in
its letter of appeal. The City will notify the Candidate in writing of its decision at the conclusion of
the review. The decision of the City is final.
If a Candidate provides the required notice of appeal and requests a hearing, the hearing shall
be conducted so that it is concluded no later than ten (10) business days after the City’s receipt
of the notice of appeal. The hearing shall be an informal process conducted by the City’s
designee, who is delegated responsibility to hear such appeals (the “Appeals Panel”). At or prior
to the hearing, the Candidate will be advised of the basis for the City’s prequalification
determination. The Candidate will be given the opportunity to present information and reasons
opposing the rating. Within two (2) business days after the conclusion of the hearing, the Appeals
Panel shall render its decision, which will be final and binding. It is the intention of the City that
the date for the submission and opening of any bids will not be delayed or postponed to allow for
completion of an appeal process.
3. PROJECT SCHEDULE
The anticipated prequalification and bidding schedule is summarized as follows:
Date Milestone
August 25, 2018 City issues Request for Statements of Qualification from Candidates
September 5, 2018 Prequalification Outreach Meeting
September 21, 2018 Deadline for submitting questions
October 9, 2018 City receives Prequalification Packages
October 29, 2018 City issues prequalified Project Bidders List and issues Notices of
Determination to Candidates.
Five days after City
notifies contractors of
ratings
Last day for Candidates to appeal City’s decision with respect to
prequalification ratings
November 20, 2018 Last day for appeals to be heard by City
November 23, 2018 City adopts Project Bidders List
January 2019 City issues Notice Inviting Bids for Project
March 2019 City receives Bids for the Project
The City may, in its sole discretion, modify the prequalification and bidding schedule.
A non-mandatory prequalification outreach meeting and site tour is scheduled for September 5,
2018, at 10:00 AM. The purpose of the prequalification outreach meeting is to introduce the
Project and the prequalification process. The prequalification meeting will be held at the City’s
Corporation Yard, 25 Prado Road, San Luis Obispo, 93401.
The prequalification outreach meeting will be broadcast via video conference for those
Candidates unable to attend in person. Details for the video broadcast and login instructions will
be posted to www.bidsync.com in advance of the meeting.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 14
City of San Luis Obispo 9 Water Resource Recovery Facility Project
Request for Statements of Qualification
4. TERMS AND CONDITIONS GOVERNING THIS RFQ
Costs of Responding; Retention by City of Questionnaires and Related Documents
The City accepts no financial responsibility for any costs incurred by a Candidate in responding
to this RFQ. Completed questionnaires and any other documents or materials submitted in
response to this RFQ shall, upon submission, become the property of the City and may be used
by the City in any way the City deems appropriate.
Reservation of Rights by City
The issuance of this RFQ does not constitute an agreement by the City that any subsequent
selection process will occur or that any contract will be entered into by the City. The City expressly
reserves the right at any time to:
Waive any defect or informality in any Prequalification Package or the procedure set forth
in this RFQ.
Reject any or all questionnaires.
Issue a new request for qualifications in lieu of this RFQ.
Change the subsequent selection process.
Procure all or any portion of the Work by any other means.
Determine that the Work will not be pursued.
The Prequalification Package, its completion and submission by the Candidate, and its use by
the City, shall not give rise to any liability on the part of the City to the Candidate or any third party
or person. This is not a solicitation for bid. No guarantees are made or implied that the Project
will be constructed, either in part or whole. The Candidate accepts all risk and cost associated
with the completion of the Prequalification Package without financial guarantee.
The City reserves the right to adjust, increase, limit, suspend or rescind any prequalification rating
based on information acquired outside of the prequalification process. Candidates whose rating
changes sufficient to disqualify them will be notified and given an opportunity for a hearing
consistent with the hearing procedures contained herein.
5. CANDIDATE QUESTIONS, REQUESTS FOR CLARIFICATION, AND REQUESTS FOR
EXCEPTIONS
In the event that a Candidate has any questions or requests for clarification the Candidate must
notify the City with its concerns no later than September 21, 2018. Should the Candidate wish to
take any exceptions regarding any part of this RFQ or its attachments, the Candidate shall follow
the procedures set forth in Section 2 of the RFQ. Questions, requests for clarification, and requests
for exceptions submitted after this date will not be considered. Questions, requests for
clarification and requests for exceptions submitted with a Prequalification Package may result in
the Prequalification Package being deemed non-responsive.
Questions regarding any aspect of this RFQ should be formally directed to the Project Manager
via the BidSync system. The City’s responses will be delivered in the form of an addendum to
this RFQ.
The City’s consideration of any exception shall not, in any way, be construed as the City’s intent
to grant said exception. Exceptions will be evaluated on a case-by-case basis and will be granted
only to correct errors in the documentation or when it is deemed to be in the best interest of the
City.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 15
City of San Luis Obispo 10 Water Resource Recovery Facility Project
Request for Statements of Qualification
6. PROJECT ADMINISTRATION
The Project Manager for this engagement is:
Project Manager: Justin Pickard, Water Systems Consulting, Inc.
Email Address: jpickard@wsc-inc.com
7. ACKNOWLEDGEMENT
The submission of a Prequalification Package shall constitute an acknowledgement upon which
the City may rely that the Candidate has thoroughly examined and is familiar with the
prequalification requirements and that the Candidate has waived any objections or contentions
regarding the RFQ document and/or the prequalification requirements set forth by the City to
determine if a Candidate is eligible to submit a bid proposal for this Project.
Candidate acknowledges receipt of the following Addenda:
Addendum Number Date Issued
By my signature below, I acknowledge receipt of this document and agree to be bound by its
terms and agree to submit it as part of the Prequalification Package.
Signature Printed Name Date
Name of contractor on whose behalf document is signed
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 16
City of San Luis Obispo Page A-1 Water Resource Recovery Facility Project
APPENDIX A
Candidate Contact Information Form
RFQ: Electrical Subcontractors for Construction of the
Water Resource Recovery Facility Project
Firm Name (as it appears on license):
Check
One:
Corporation Partnership Sole Proprietor
Name of Contact Person:
Street Address:
City:
State:
Zip:
Phone:
Fax:
Email Address:
Contractor’s License Number(s) and Expiration Date(s):
Tax ID Number:
General Tax Exemption Number:
Dun and Bradstreet Number (if applicable):
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 17
City of San Luis Obispo Page A-2 Water Resource Recovery Facility Project
If firm is a partnership or sole proprietor:
Owner of Company:
Responsible Managing Employee Name:
Responsible Managing Employee License Number and Expiration Date:
THIS DOCUMENT IS SUBJECT TO DISCLOSURE
TO THIRD PARTIES
Each prospective Candidate must have an Electrical Contractor Class “C‐10” California Contractor’s license
which is current, active and in good standing with the California Contractors State License Board (CSLB), on
the date and time the request for qualifications submittal is due and must submit this request for
qualification with all portions completed, including required attachments. Each prospective Candidate must
answer all of the following questions and provide all requested information, where applicable. Any
prospective Candidate failing to do so may be deemed unqualified to submit a proposal. It is critical that
prospective a Candidate fill out all information required accurately, completely, truthfully and to the best of
its knowledge. Ambiguous or incomplete information may lead to an unfavorable evaluation resulting in a
determination of non‐responsibility.
The undersigned hereby agrees and declares that receipt of this submittal by the City of San
Luis Obispo does not constitute either a direct or implied guarantee that Prequalification is or
will be granted.
I, the undersigned, certify and declare that I have read all the foregoing answers to this
prequalification questionnaire and know their contents. The matters stated in the questionnaire
answers are true of my own knowledge and belief, except as to those matters stated on
information and belief, and as to those matters I believe them to be true. I declare under penalty
of perjury under the laws of the State of California, that the foregoing is correct.
The undersigned is a legally authorized representative of the Candidate for the legal name
noted above.
Candidate
Signature Date
Printed Name/Title
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 18
City of San Luis Obispo Page A-3 Water Resource Recovery Facility Project
Subscribed and sworn to before me this day of , 20
Notary Public in and for the State of:
Residing at:
Expiration Date:
**END OF CANDIDATE CONTACT INFORMATION FORM**
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 19
City of San Luis Obispo Page B-1 Water Resource Recovery Facility Project
APPENDIX B
Prequalification Questionnaire
RFQ: Electrical Subcontractors for Construction of the
Water Resource Recovery Facility Project
Candidates will need to demonstrate specific, relevant experience as an electrical contractor on
construction of wastewater, recycled water, or potable water treatment facilities similar in size,
scope and complexity to the Water Resource Recovery Facility Project (“Project”). Candidates
shall complete Parts I, II and III of the Prequalification Questionnaire, per the instructions detailed
below. It is expected that the Candidate shall self-perform the electrical portion of the Work.
For Candidates forming joint ventures, each member of the joint venture must be individually pre-
qualified as Qualified Candidates
Those Candidates who are evaluated to be qualified to perform the Project based on the
submitted Prequalification Questionnaire (Qualified Candidates) will be eligible to submit bids to
prequalified general contractors for the Project.
Instructions for completing the Prequalification Questionnaire
If additional sheets are necessary to complete the questionnaire, Candidates shall use 8-½ in. x
11 in. paper, attached in order, and shall reference the section and question being answered.
Candidates shall sign each additional sheet.
PART I – ESSENTIAL REQUIREMENTS FOR QUALIFICATION
PART II – INFORMATION REGARDING THE ORGANIZATION, HISTORY, PERFORMANCE,
AND COMPLIANCE WITH CIVIL AND CRIMINAL LAWS
A. Current Organization and Structure of the Business
Candidates must respond to each question.
B. History of the Business and Organizational Performance
Candidates must respond to each question.
C. Licenses
Candidates must respond to each question.
D. Disputes
Candidates must respond to each question.
E. Criminal Matters and Related Civil Suits
Candidates must respond to each question.
F. Bonding
Candidates must provide the requested information and respond to each question.
G. Compliance with Occupational Safety and Health Laws and with Other Labor and Safety
Legislation
Candidates must provide the requested information and respond to each question.
H. Prevailing Wage and Apprenticeship Compliance Record
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 20
City of San Luis Obispo Page B-2 Water Resource Recovery Facility Project
Candidates must respond to each question.
PART III – MANDATORY PROJECT EXPERIENCE
Candidates must complete all of the questions.
All questions are pass/fail with criteria for passing listed for each question. Candidates must pass
all questions in order to be qualified to submit a Bid on the project.
Using the Project Data Sheet (see Appendix C), Candidates must provide two (2) project
references to validate the response to Part A, Questions 1 and 2, and one (1) project reference
for each project to validate the response to Part B, Questions 3 through 5. For projects completed
by the Candidate as a member of a joint venture, Candidate shall indicate percent ownership of
the joint venture and indicate the type and percentage of the work completed by the Candidate.
Project references provided by the Candidate in response to Part, Question 1, may be used to
satisfy the project reference requirements for Part A, Question 2, and Part B, Questions 3 through
5.
The City will forward a questionnaire entitled “Project Reference Questionnaire” directly to the
project owners identified in each Project Data Sheet. Each owner will be asked to complete and
return the questionnaire directly to the City (see Appendix E for a sample Project Reference
Questionnaire). The individual furnishing the information in the Project Reference Questionnaire
shall be the project managers or the heads of the department in charge of the construction of the
projects listed. These individuals must have personal knowledge of the Candidate’s performance
on the project. The City reserves the right to seek additional information from any individual who
has information about the listed projects.
To effectuate the candid completion of information requested in the Project Reference
Questionnaire, Candidates are required to execute and submit the attached Release and Waiver
Agreement (Appendix D) in favor of each individual furnishing information requested in the
Questionnaire.
The Candidates shall verify that all previous project contact information listed is current and
accurate. Failure of the Candidate to provide current and accurate project contact information
may be grounds for the City to determine the Candidate as non-responsive and ineligible for
further prequalification consideration. The City will not research current contact information on the
Candidate’s behalf. It is the responsibility of the Candidates to ensure that the named reference
individuals will respond in a timely manner and furnish the information requested in the Project
Reference Questionnaire within the RFQ schedule. Candidate’s Prequalification Package shall
be deemed nonresponsive if, without limitation, the Project Reference Questionnaires from the
referenced individuals are not returned on time or do not provide all requested information.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 21
City of San Luis Obispo Page B-3 Water Resource Recovery Facility Project
PART I. ESSENTIAL REQUIREMENTS FOR QUALIFICATION
An answer of “no” to any of the Questions 1 through 3 will be rated a “Fail” and the Candidate will
be immediately disqualified.
An answer of “yes” to any of the Questions 4 through 13 below will be rated a “Fail” and the
Candidate will be immediately disqualified.
1. Does your firm possess a valid and current Electrical “C-10” California Contractor’s
license?
Yes No
2. Will the Candidate comply with and provide all insurance as defined in Appendix H “City
Minimum Insurance Requirements”?
Yes No
NOTE: Candidate shall furnish a statement indicating the contractor’s ability to
provide the insurance provided as Appendix H. The Candidate will be required to
provide insurance as provided for in the Contract Documents upon actual bid and
award.
3. Has the Candidate attached a notarized statement from an admitted surety insurer
(approved by the California Department of Insurance) authorized to transact surety
business in the State of California, which states the Candidate’s current total available
bonding capacity and individual project bonding capacity?
Yes No
NOTE: Candidate shall furnish a notarized statement from the surety company, not
an agent or broker, similar to the sample certification provided as Appendix I. A
notarized statement from the Candidate’s surety is being requested in lieu of an
audited financial statement to verify the financial fitness of the Candidate. Please
note that the provision of a performance and/or payment bond from the electrical
subcontractor will be at the discretion of the general contractor.
4. Has the Candidate’s contractor’s license been revoked at any time in the last five (5)
years?
Yes No
5. During the last eight (8) years, has your firm ever been denied performance and payment
bonds by a surety company because of the surety's determination that the entity failed to
perform adequately on an existing or prior project?
Yes No
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 22
City of San Luis Obispo Page B-4 Water Resource Recovery Facility Project
6. Has a surety firm completed a contract on the Candidate’s behalf, or paid for completion
because the Candidate was terminated for default by the project owner or the Candidate
was otherwise unable to complete a contract within the last five (5) years?
Yes No
7. Has your contractor’s license been revoked or suspended at any time for more than 90
days in the last five (5) years, pursuant to Article 7 of the California Business and
Professional Code (construction without a permit, failure to pay civil penalties or
compliance with order or correction, etc.)?
Yes No
8. At the time of submitting this prequalification form, is the Candidate ineligible to bid on or
be awarded a public works contract, or perform as a subcontractor on a public works
contract, pursuant to either Labor Code section 1777.1 or Labor Code Section 1777.7?
Yes No
If the answer is “Yes,” state the beginning and ending dates of the period of debarment:
9. Is your firm, or any owners or officers of your firm, currently listed on the State Water
Board’s List of Disqualified Businesses and Persons?
Yes No
10. At any time during the last five (5) years, has the Candidate or any of its owners, or officers
been convicted of a crime involving the bidding, award or performance of a government
contract?
Yes No
11. At any time during the last eight (8) years, has your firm, or any owners or officers of your
firm, been found liable in civil or criminal court for false claims, material misrepresentation,
dishonesty, or fraud against a public entity?
Yes No
12. In the last five (5) years, has your firm been debarred, disqualified, removed or otherwise
prevented from bidding on, from being awarded or from completing, any public work or
government project for any reason?
Note: “Associated with” refers to another construction firm in which an owner,
partner or officer of your firm held an ownership, principal, or management
position, and which is listed in response to question Part II, Section A on this form.
Yes No
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 23
City of San Luis Obispo Page B-5 Water Resource Recovery Facility Project
13. List your firm’s Experience Modification Rate (EMR) (California workers’ compensation
insurance) issued to your firm annually by your workers’ compensation insurance carrier
for the current year:
Current year: ____________________
Is your current year EMR higher than 1.00?
Yes No
Note: Verification of your EMR must be provided as detailed in Section II,
Paragraph G, Question 32.
END OF PART I
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 24
City of San Luis Obispo Page B-6 Water Resource Recovery Facility Project
PART II. INFORMATION REGARDING THE ORGANIZATION, HISTORY,
PERFORMANCE, AND COMPLIANCE WITH CIVIL AND CRIMINAL LAWS
A. Current Organization and Structure of the Business
For Candidates That Are Corporations:
1a. Date incorporated:
1b. Under the laws of what state:
1c. Provide all the following information for each person who is either (a) an officer of the
corporation (president, vice president, secretary, treasurer), or (b) the owner of at least
ten (10) percent of the corporation’s stock.
Name Position Years with Co. % Ownership
1d. Identify every construction, equipment manufacturer, or material supply firm that any
person listed above has been associated with (as owner, general partner, limited partner
or officer) at any time during the last five (5) years.
NOTE: For this question, “owner” and “partner” refer to ownership of ten (10)
percent or more of the business, or ten (10) percent or more of its stock, if the
business is a corporation.
Name Name of Company
Dates of Person’s
Participation with
Company
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 25
City of San Luis Obispo Page B-7 Water Resource Recovery Facility Project
For Candidates That Are Partnerships:
1a. Date of formation:
1b. Under the laws of what state:
1c. Provide all the following information for each partner who owns ten (10) percent or more
of the firm.
Name Position Years with Co. % Ownership
1d. Identify every construction, equipment manufacturer, or material supply company that any
partner has been associated with (as owner, general partner, limited partner or officer) at
any time during the last five (5) years.
NOTE: For this question, “owner” and “partner” refer to ownership of ten (10)
percent or more of the business, or ten (10) percent or more of its stock, if the
business is a corporation.
Name Name of Company
Dates of Person’s
Participation with
Company
For Candidates That Are Sole Proprietorships:
1a. Date of commencement of business:
1b. Identify every construction, equipment manufacturer, or material supply firm that the
business owner has been associated with (as owner, general partner, limited partner or
officer) at any time during the last five (5) years.
NOTE: For this question, “owner” and “partner” refer to ownership of ten (10)
percent or more of the business, or ten (10) percent or more of its stock, if the
business is a corporation.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 26
City of San Luis Obispo Page B-8 Water Resource Recovery Facility Project
Name Position Years with Co. % Ownership
B. History of the Business and Organizational Performance
2. Has there been any change in ownership of the Candidate’s firm at any time during the
last five (5) years?
NOTE: A corporation whose shares are publicly traded is not required to answer
this question.
Yes No
If “yes,” explain on a separate signed page.
3. Is the Candidate a subsidiary, parent, holding company or affiliate of another construction,
equipment manufacturer, or material supply firm?
NOTE: Include information about other firms if one firm owns 50 percent or more
of another, or if an owner, partner, or officer of the Candidate holds a similar
position in another firm.
Yes No
If “yes”, and a firm seeks to prequalify based on the financial status or the experience of
an affiliate or parent company, that affiliate or parent company will be required to provide
an affidavit guaranteeing the contract performance of the prequalifying firm in every
respect including indemnity. Provide a detailed explanation on a separate signed page.
4. Are any corporate officers, partners or owners connected to any other construction,
equipment manufacturer, or material supply firms?
NOTE: Include information about other firms if an owner, partner, or officer of the
Candidate holds a similar position in another firm.
Yes No
If “yes,” explain on a separate signed page.
5. State the Candidate’s gross revenues for each of the last three (3) years:
Year Gross Revenue
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 27
City of San Luis Obispo Page B-9 Water Resource Recovery Facility Project
6. How many years has the Candidate been in business in California as a Candidate under
the Candidate’s present business name and license number?
Years
7. Is the Candidate currently the debtor in a bankruptcy case?
Yes No
If “yes,” please attach a copy of the bankruptcy petition, showing the case number, and
the date on which the petition was filed.
8. Was the Candidate in bankruptcy at any time during the last five (5) years? This question
refers only to a bankruptcy action that was not described in answer to question 7, above.
Yes No
If “yes,” please attach a copy of the bankruptcy petition, showing the case number and the
date on which the petition was filed, and a copy of the Bankruptcy Court’s discharge order,
or of any other document that ended the case, if no discharge order was issued.
C. Licenses
9. List all California construction license numbers, classifications and expiration dates of the
California contractor licenses held by the Candidate. At a minimum, Candidates shall
possess a valid Class C-10 – Electrical Contractor’s License to be considered.
License Number Classification Expiration Date
10. If any of the Candidate’s license(s) are held in the name of a corporation or partnership,
list below the names of the qualifying individual(s) listed on the California Contractors
State Licensing Board (CSLB) records who meet(s) the experience and examination
requirements for each license.
License Number Classification Name of Qualifying
Individual(s)
Expiration Date
11. Has the Candidate changed names or license number in the past five (5) years?
Yes No
If “yes,” explain on a separate signed page, including the reason for the change.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 28
City of San Luis Obispo Page B-10 Water Resource Recovery Facility Project
12. Has any owner, partner or (for corporations) officer of the Candidate operated a
construction, equipment manufacturer, or material supply firm under any other name in
the last five (5) years?
Yes No
If “yes,” explain on a separate signed page, including the reason for the change.
13. Has any CSLB license held by the Candidate or its Responsible Managing Employee
(RME) or Responsible Managing Officer (RMO) been suspended or revoked within the
last five (5) years?
Yes No
If “yes,” please explain on a separate signed sheet.
D. Disputes
14. At any time in the last five (5) years has the Candidate been assessed liquidated damages
under a construction contract with either a public or private owner?
Yes No
If yes, explain on a separate signed page, identifying all such projects by owner, owner’s
address, the date of completion of the project, amount of liquidated damages assessed
and all other information necessary to fully explain the assessment of liquidated damages.
15. In the last five (5) years has the Candidate been denied an award of a public works
contract based on a finding by a public agency that the Candidate was not a responsible
bidder?
Yes No
If “yes,” explain on a separate signed page. Identify the year of the event, the owner, the
project and the basis for the finding by the public agency.
16. In the past five (5) years has any action against the Candidate concerning the Candidate’s
performance of a construction project been filed in court or arbitration?
Yes No
If “yes,” on separate signed sheets of paper identify the claim(s) by providing the project
name, date of the claim, name of the claimant, a brief description of the nature of the claim,
the court in which the case was filed and a brief description of the status of the claim
(pending or, if resolved, a brief description of the resolution). If “yes”, are there any current
claims against the Candidate that should you lose the claim(s), would adversely affect the
Candidate’s financial position or the Candidate’s ability to meet the Candidate’s
obligations if awarded the contract for this project? If so, please explain.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 29
City of San Luis Obispo Page B-11 Water Resource Recovery Facility Project
17. In the past five (5) years has the Candidate made any claim against a project owner
concerning work on a project or payment for a contract and filed an action in court or
arbitration?
Yes No
If “yes,” on separate signed sheets of paper identify the claim by providing the project
name, date of the claim, name of the entity (or entities) against whom the claim was filed,
a brief description of the nature of the claim, the court in which the case was filed and a
brief description of the status of the claim (pending, or if resolved, a brief description of
the resolution). If “yes”, are there any current claims against a project owner that should
the Candidate lose the claim(s), would adversely affect the Candidate’s financial position
or the Candidate’s ability to meet the Candidate’s obligations if awarded the contract for
this project? If so, please explain.
18. At any time during the past five (5) years, has any surety company made any payments
on the Candidate’s behalf, to satisfy any claims made against a performance or payment
bond issued on the Candidate’s behalf, in connection with a construction project, either
public or private?
Yes No
If “yes,” explain on a separate signed page the amount of each such claim, the name and
telephone number of the claimant, the date of the claim, the grounds for the claim, the
present status of the claim, the date of resolution of such claim if resolved, the method by
which such was resolved if resolved, the nature of the resolution and the amount, if any,
at which the claim was resolved.
19. In the last five (5) years has any insurance carrier, for any form of insurance, refused to
renew the insurance policy for the Candidate?
Yes No
If “yes,” explain on a separate signed page. Name the insurance carrier, the form of
insurance and the year of each refusal.
E. Criminal Matters and Related Civil Suits
20. Has the Candidate or any of its owners, officers or partners ever been convicted of a crime
involving any federal, state, or local law related to construction?
Yes No
If “yes,” explain on a separate signed page, including identifying who was involved, the
name of the public agency, the date of the conviction and the grounds for the conviction.
21. Has the Candidate or any of its owners, officers or partners ever been convicted of a
federal or state crime of fraud, theft, or any other act of dishonesty?
Yes No
If “yes,” identify on a separate signed page the person or persons convicted, the court
(the county if a state court, the district or location of the federal court), the year and the
criminal conduct.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 30
City of San Luis Obispo Page B-12 Water Resource Recovery Facility Project
F. Bonding
22. Attach a certified statement from a bonding firm authorized to do business in the State of
California. The certification shall be submitted in original form and must indicate the
maximum bonding coverage the surety will issue on the applicant’s behalf for a single
contract, and shall also specify the total bonding that the surety will issue for all of the
Candidate’s work, including uncompleted contracts, and the Candidate’s current bonding
capacity is sufficient for this Project for which the Candidate is seeking prequalification. A
sample Certification of Surety is included as Appendix I to this RFQ. Minimum bonding
for this Project is currently estimated at $25 million.
23. If the Candidate was required to pay a premium of more than one (1) percent for a
performance and payment bond on any project(s) on which the Candidate worked at any
time during the last five (5) years, state the percentage that the Candidate was required
to pay. The Candidate may provide an explanation for a percentage rate higher than one
(1) percent, if the Candidate wishes to do so.
24. List all other sureties (name and full address) that have written bonds for the Candidate
during the last five (5) years, including the dates during which each wrote the bonds:
25. During the last five (5) years, has the Candidate ever been denied bond coverage by a
surety company, or has there ever been a period of time when the Candidate had no
surety bond in place during a public construction project when one was required?
Yes No
If yes, provide details on a separate signed sheet indicating the date when the Candidate
was denied coverage and the name of the company or companies which denied coverage;
and the period during which the Candidate had no surety bond in place.
G. Compliance with Occupational Safety and Health Laws and with Other Labor
Legislation Safety
26. Has Cal/OSHA cited and assessed penalties against the Candidate for any “serious,”
“willful” or “repeat” violations of its safety or health regulations in the past five (5) years?
Yes No
If “yes,” attach a separate signed page describing the citations, including information about
the dates of the citations, the nature of the violation, the project on which the citation(s)
was or were issued, and the amount of penalty paid, if any. If the citation was appealed to
the Occupational Safety and Health Appeals Board and a decision has been issued, state
the case number and the date of the decision.
27. Has the federal Occupational Safety and Health Administration cited and assessed
penalties against the Candidate in the past five (5) years?
Yes No
If “yes,” attach a separate signed page describing each citation.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 31
City of San Luis Obispo Page B-13 Water Resource Recovery Facility Project
28. As a result of the Candidate’s actions or inactions, has the EPA or any Air Quality
Management District or any Regional Water Quality Control Board cited and assessed
penalties against either the Candidate or the owner of a project on which the Candidate
was the contractor, in the past five (5) years?
Yes No
If “yes,” attach a separate signed page describing each citation.
29. How often does the Candidate require documented safety meetings to be held for
construction employees and field supervisors during the course of a project?
30. Experience Modification Rate (EMR): Please obtain a letter from the Candidate’s
insurance carrier (or state fund if applicable) with the Candidate’s interstate EMR’s for the
last three (3) years. If the Candidate does not have an interstate rating, obtain the
Candidate’s intrastate EMRs. Attach the letter as part of this package. The Candidate shall
list the Experience Modification Rate for the last three years (available from the
Candidate’s insurance carrier).
Year EMR
Three Year Average =
Are the above rates interstate or intrastate?
NOTE: Any of the following methods of “obtaining a letter” are acceptable:
(1) Furnish a letter from the Candidate’s insurance agent, insurance carrier or state
fund (on their letterhead) verifying the EMR data listed above; or
(2) Furnish a photocopy of the applicable Experience Rating Calculation Sheets,
which the Candidate’s insurance carrier should forward to the Candidate annually.
31. Within the last five (5) years has there ever been a period when the Candidate had
employees but was without workers’ compensation insurance or state-approved self-
insurance?
Yes No
If “yes,” please explain the reason for the absence of workers’ compensation insurance
on a separate signed page. If “no,” please provide a statement by the Candidate’s current
workers’ compensation insurance carrier that verifies periods of workers’ compensation
insurance coverage for the last five (5) years. (If the Candidate has been in the
construction business for less than five (5) years, provide a statement by the Candidate’s
workers’ compensation insurance carrier verifying continuous workers’ compensation
insurance coverage for the period that the Candidate has been in the construction
business.)
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 32
City of San Luis Obispo Page B-14 Water Resource Recovery Facility Project
H. Prevailing Wage and Apprenticeship Compliance Record
32. Has the Candidate been required at any time during the last five (5) years to pay either
back wages or penalties for the Candidate’s own firm’s failure to comply with California’s
prevailing wage laws?
NOTE: This question refers only to the Candidate’s own firm’s violation of
prevailing wage laws, not to violations of the prevailing wage laws by a
subcontractor.
Yes No
If ”yes,” attach a separate signed page or pages, describing the nature of each violation,
identifying the name of the project, the date of its completion, the public agency for which
it was constructed, the number of employees who were initially underpaid and the amount
of back wages and penalties that the Candidate was required to pay.
33. During the last five (5) years, has the Candidate’s own firm has been penalized or required
to pay back wages for failure to comply with the federal Davis-Bacon prevailing wage
requirements?
Yes No
If “yes,” attach a separate signed page or pages describing the nature of the violation,
identifying the name of the project, the date of its completion, the public agency for which
it was constructed, the number of employees who were initially underpaid, the amount of
back wages the Candidate was required to pay along with the amount of any penalty paid.
34. At any time during the last five (5) years, has the Candidate been found to have violated
any provision of California apprenticeship laws or regulations, or the laws pertaining to
use of apprentices on public works?
NOTE: The Candidate may omit reference to any incident that occurred if the
violation was by a subcontractor and the Candidate, as general contractor on a
project, had no knowledge of the subcontractor’s violation at the time it occurred.
Yes No
If “yes,” provide the date(s) of such findings, and attach copies of the Department’s final
decision(s).
END OF PART II
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 33
City of San Luis Obispo Page B-15 Water Resource Recovery Facility Project
PART III. MANDATORY PROJECT EXPERIENCE
Candidates must complete Questions 1 through 6 in this section. In the case of joint ventures,
each joint venture partner must complete Questions 1 through 5. Questions 1 through 5 in this
section are pass/fail with criteria for passing listed for each question. Candidates must pass all
questions in this section in order to be qualified to submit a Bid for the Project.
Using the Project Data Sheet (see Appendix C), Candidates (each partner for joint ventures) must
provide two (2) project references to validate the responses to Questions 1 and 2 and one (1)
project reference for each project to validate the response to Questions 3 through 5. Please note
the projects provided as references for Question 1 can be used as references for Questions 2
through 5 where applicable. Candidates (each partner for joint ventures) must provide at least
two (2) different reference projects.
The City will forward a questionnaire entitled “Project Reference Questionnaire,” directly to the
list of Project owners specified in each Project Data Sheet. Each owner will be asked to complete
and return the questionnaire directly to the City (see Appendix E for a sample Project Reference
Questionnaire). The individual furnishing the information in the Project Reference Questionnaire
shall be the project managers or the heads of the department in charge of the construction of the
projects listed. These individuals must have personal knowledge of the Candidate’s performance
on the project. The City reserves the right to seek additional information from any individual who
has information about the listed projects.
Candidates are required to score a minimum of 122 points out of a possible 175 points on
each Project Reference Questionnaire to be qualified to proceed with the evaluation
process.
To effectuate the candid completion of information requested in the Project Reference
Questionnaire, Candidates are required to execute and submit the attached Release and Waiver
Agreement (Appendix D) in favor of each individual furnishing information requested in the
Questionnaire.
A. Firm Experience
1. Has your firm completed electrical work for construction of at least two (2) municipal
treatment facilities (wastewater, recycled water, or potable water) treatment facility
construction projects within the past ten (10) years that meet all the following criteria:
Your firm self-performed at least 75% of the electrical work (based on total craft hours);
Construction took place within an active treatment facility that remained in operation
during construction [for one (1) of the two (2) reference projects]; and
Electrical subcontract value was at least $10 million?
Note: Contract values for projects completed prior to January 1, 2018, can be
converted to equivalent 2018 costs by utilizing the Engineering News Record (ENR)
Construction Cost Index (20-city average) in accordance with the following formula:
INDEX 2018 x Cost (year completed) = Cost 2018
INDEX (year completed)
Where:
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 34
City of San Luis Obispo Page B-16 Water Resource Recovery Facility Project
INDEX 2018 corresponds to the ENR CCI for January 2018
INDEX (year completed) corresponds to the ENR CCI for the month and year when the
project was completed
Cost (year completed) is the final construction cost at the completion of the project,
including change orders
Candidate (each partner if a joint venture) must meet the requirements of this question on
its own as a firm/entity; the City will not consider the experience/qualifications of other joint
venture partners, subcontractors, or Candidate’s employees when evaluating the
Candidate's (each partner’s if a joint venture) qualifications in response to this question.
Yes No
If “no”, your firm is not qualified to submit a Bid on the Project.
List the qualifying projects, citing the following: project name, project owner, original and
final contract amount, original and final contract time, project scope including the type and
size of the facility, percentage of the electrical work self-performed, and year of
completion.
Complete and submit a Project Data Sheet (Appendix C) for each of the projects
listed below.
Project 1:
Project 2:
2. Has your firm completed the construction of at least two (2) projects within the last fifteen
(15) years that included the installation of medium voltage (1 kV to 35 kV) switchgear and
medium voltage conductors with a minimum electrical contract value of $2 million for which
your firm self-performed at least 50% of the electrical work?
Candidate (each partner if a joint venture) must meet the requirements of this question on
its own as a firm/entity; the City will not consider the experience/qualifications of other joint
venture partners, subcontractors, or Candidate’s employees when evaluating the
Candidate's (each partner’s if a joint venture) qualifications in response to this question.
Yes No
If “no”, your firm is not qualified to submit a Bid on the Project.
List the qualifying project, citing the following: project name, project owner, original and
final contract amount, project scope, percentage of the work self-performed, and year of
completion.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 35
City of San Luis Obispo Page B-17 Water Resource Recovery Facility Project
Complete and submit a Project Data Sheet for each of the projects listed below.
Project 3:
Project 4:
B. Key Personnel Experience
3. Does your proposed Project Manager have at least ten (10) years of experience managing
electrical construction for complex treatment facility projects (wastewater, recycled water,
or potable water) including at least one (1) project with a contract value of $10 million or
greater and has the proposed Project Manager been employed by your firm for at least
one (1) year?
Candidate (each partner if a joint venture) must meet the requirements of this question
with its own employees; the City will not consider the experience/qualifications of
employees of other joint venture partners or subcontractors.
Yes No
If “no”, your firm is not qualified to submit a Bid on the project.
List the qualifying project, citing the following: project name, project owner, original and
final contract amount, project scope, percentage of the work self-performed, and year of
completion.
Complete and submit a Project Data Sheet for the project listed below.
Project 5:
4. Has your proposed Project Manager managed a project that included the installation of
medium voltage (1kV to 35 kV) switchgear and medium voltage conductors?
Candidate (each partner if a joint venture) must meet the requirements of this question
with its own employees; the City will not consider the experience/qualifications of
employees of other joint venture partners or subcontractors.
Yes No
If “no”, your firm is not qualified to submit a Bid on the project.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 36
City of San Luis Obispo Page B-18 Water Resource Recovery Facility Project
List the qualifying project, citing the following: project name, project owner, original and
final contract amount, project scope, percentage of the work self-performed, and year of
completion.
Complete and submit a Project Data Sheet for the project listed below.
Project 6:
5. Does your proposed Superintendent for this Project have at least seven (7) years of
experience constructing electrical systems for complex treatment facility projects
(wastewater, recycled water, or potable water) including at least one (1) project with a
contract value of $10 million or greater and has the proposed Superintendent been
employed by your firm for at least one (1) year?
Candidate (each partner if a joint venture) must meet the requirements of this question
with its own employees; the City will not consider the experience/qualifications of
employees of other joint venture partners or subcontractors.
Yes No
If “no”, your firm is not qualified to submit a Bid on the project.
List the qualifying project, citing the following: project name, project owner, original and
final contract amount, project scope, percentage of the work self-performed, and year of
completion.
Complete and submit a Project Data Sheet for the project listed below.
Project 7:
6. List the qualifying Project Manager and Superintendent proposed for this Project below.
Complete and submit a Key Personnel Data Sheet (Appendix G) for each of the
individuals listed below.
Project Manager
Superintendent(s)
In the event that changes to key lead personnel occur after a Candidate has been
designated as qualified to bid, Candidate shall provide at least three (3) resumes (using
Appendix G resume forms) of proposed candidate replacement personnel in advance of
submitting its bid. Proposed replacement personnel shall have qualifications that meet or
exceed those of the personnel being replaced, as determined by the City. The City
reserves the right to exclude any prospective Bidder or reject any bid in the event that
there are differing key personnel from those which were pre-qualified.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 37
City of San Luis Obispo Page B-19 Water Resource Recovery Facility Project
END OF PART III
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 38
City of San Luis Obispo Page C-1 Water Resource Recovery Facility Project APPENDIX C Project Data Sheet Performance Record RFQ: Electrical Subcontractors for Construction of the Water Resource Recovery Facility Project As directed in the Pre-Qualification Questionnaire instruction for Part III, Candidates (each partner if a joint venture) must provide a minimum of two (2) project references to validate the responses to Questions 1 and 2. If the two (2) project references provided for Questions 1 and 2 do not meet the requirements of Questions 3 through 5, Candidates must provide additional reference projects to validate the responses to those questions. Resolution No. 10930 (2018 Series) EXHIBIT APage 39
City of San Luis Obispo Page C-2 Water Resource Recovery Facility Project Project Reference 1 of 2 for Part III-A, Question 1: To be considered for pre-qualification, Candidate (each partner if a joint venture) shall have completed at least two (2) municipal treatment facility projects (wastewater, recycled water, and/or potable water) each within the past ten (10) years for which your firm self-performed at least 75% of the electrical work, construction took place within an active treatment facility that remained in operation during construction [for one (1) of the three (3) reference projects], and the contract value was at least $10 million. Candidate (each partner if a joint venture) shall list such projects below. No. Item Description Project No. 1 1 Project Name/Location 2 Owner (Reference) – Contact Info: Name/Address/Telephone/e-mail 3 General Contractor (Contact Name/Address/Telephone/e-mail) 4 Names of JV Partners/Major Subs Performing more than 10% of the Work 5 Roles of JV Partners/Major Subs 6 Names of Project Manager and Superintendents 7 Engineering Firm (Contact Name/Address/Telephone/e-mail) 8 Construction Manager (Contact Name/Address/Telephone/e-mail) Resolution No. 10930 (2018 Series) EXHIBIT APage 40
City of San Luis Obispo Page C-3 Water Resource Recovery Facility Project No. Item Description Project No. 1 9 Treatment Facility: Wastewater, Recycled Water, or Potable Water Total Operating Capacity (million gallons per day - mgd) Treatment Processes 10 Description of Project, Scope of Electrical Work Performed 11 Contract Award Date 12 Substantial Completion Date 13 Original Contract Period (calendar days) 14 Actual Construction Time (calendar days) 15 Reason for Delays 16 Electrical Portion of Contract Bid Price 17 Final Electrical Work Portion of Construction Cost (Actual Cost and ENR CCI Adjusted Cost) Basis for Increase or Decrease in Final Electrical Work Construction Cost Resolution No. 10930 (2018 Series) EXHIBIT APage 41
City of San Luis Obispo Page C-4 Water Resource Recovery Facility Project No. Item Description Project No. 1 18 Number of Electrical Work Related Claims Filed (and who filed: Owner or Contractor) 19 Description and % of the Work Self-Performed 20 Facility Remained in Operation During Construction (yes or no) Supplementary information - please provide any other explanatory notes on the above topics considered relevant on a separate sheet. Resolution No. 10930 (2018 Series) EXHIBIT APage 42
City of San Luis Obispo Page C-5 Water Resource Recovery Facility Project Project Reference 2 of 2 for Part III-A, Question 1: To be considered for pre-qualification, Candidate (each partner if a joint venture) shall have completed at least two (2) municipal treatment facility projects (wastewater, recycled water, and/or potable water) each within the past ten (10) years for which your firm self-performed at least 75% of the work, construction took place within an active treatment facility that remained in operation during construction [for one (1) of the three (3) reference projects], and the contract value was at least $10 million. Candidate (each partner if a joint venture) shall list such projects below. No. Item Description Project No. 2 1 Project Name/Location 2 Owner (Reference) – Contact Info: Name/Address/Telephone/e-mail 3 General Contractor (Contact Name/Address/Telephone/e-mail) 4 Names of JV Partners/Major Subs Performing more than 10% of the Work 5 Roles of JV Partners/Major Subs 6 Names of Project Manager and Superintendents 7 Engineering Firm (Contact Name/Address/Telephone/e-mail) 8 Construction Manager (Contact Name/Address/Telephone/e-mail) Resolution No. 10930 (2018 Series) EXHIBIT APage 43
City of San Luis Obispo Page C-6 Water Resource Recovery Facility Project No. Item Description Project No. 2 9 Treatment Facility: Wastewater, Recycled Water, or Potable Water Total Operating Capacity (million gallons per day - mgd) Treatment Processes 10 Description of Project, Scope of Electrical Work Performed 11 Contract Award Date 12 Substantial Completion Date 13 Original Contract Period (calendar days) 14 Actual Construction Time (calendar days) 15 Reason for Delays 16 Electrical Portion of Contract Bid Price 17 Final Electrical Work Portion of Construction Cost (Actual Cost and ENR CCI Adjusted Cost) Basis for Increase or Decrease in Final Electrical Work Construction Cost Resolution No. 10930 (2018 Series) EXHIBIT APage 44
City of San Luis Obispo Page C-7 Water Resource Recovery Facility Project No. Item Description Project No. 2 18 Number of Electrical Work Related Claims Filed (and who filed: Owner or Contractor) 19 Description and % of the Work Self-Performed 20 Facility Remained in Operation During Construction (yes or no) Supplementary information - please provide any other explanatory notes on the above topics considered relevant on a separate sheet. Resolution No. 10930 (2018 Series) EXHIBIT APage 45
City of San Luis Obispo Page C-8 Water Resource Recovery Facility Project Project Reference 1 of 2 for Part III-A, Question 2: To be considered for pre-qualification, Candidate (each partner if a joint venture) shall have completed construction of at least two (2) projects within the last fifteen (15) years that included the installation of medium voltage (1 kV to 35 kV) switchgear and medium voltage conductors with a minimum electrical contract value of $2 million for which your firm self-performed at least 50% of the electrical work. Candidate (each partner if a joint venture) shall list such projects below. No. Item Description Project No. 3 1 Project Name/Location 2 Owner (Reference) – Contact Info: Name/Address/Telephone/e-mail 3 General Contractor (Contact Name/Address/Telephone/e-mail) 4 Names of JV Partners/Major Subs Performing more than 10% of the Work 5 Roles of JV Partners/Major Subs 6 Names of Project Manager and Superintendents 7 Engineering Firm (Contact Name/Address/Telephone/e-mail) 8 Construction Manager (Contact Name/Address/Telephone/e-mail) Resolution No. 10930 (2018 Series) EXHIBIT APage 46
City of San Luis Obispo Page C-9 Water Resource Recovery Facility Project No. Item Description Project No. 3 9 Description of Project, Scope of Electrical Work Performed 10 Contract Award Date 11 Substantial Completion Date 12 Original Contract Period (calendar days) 13 Actual Construction Time (calendar days) 14 Reason for Delays 15 Electrical Portion of Contract Bid Price 16 Final Electrical Work Portion of Construction Cost (Actual Cost and ENR CCI Adjusted Cost) Basis for Increase or Decrease in Final Electrical Work Construction Cost Resolution No. 10930 (2018 Series) EXHIBIT APage 47
City of San Luis Obispo Page C-10 Water Resource Recovery Facility Project No. Item Description Project No. 3 17 Number of Electrical Work Related Claims Filed (and who filed: Owner or Contractor) 18 Description and % of the Work Self-Performed Supplementary information - please provide any other explanatory notes on the above topics considered relevant on a separate sheet. Resolution No. 10930 (2018 Series) EXHIBIT APage 48
City of San Luis Obispo Page C-11 Water Resource Recovery Facility Project Project Reference 2 of 2 for Part III-A, Question 2: To be considered for pre-qualification, Candidate (each partner if a joint venture) shall have completed construction of at least two (2) projects within the last fifteen (15) years that included the installation of medium voltage (1 kV to 35 kV) switchgear and medium voltage conductors with a minimum electrical contract value of $2 million for which your firm self-performed at least 50% of the electrical work. Candidate (each partner if a joint venture) shall list such projects below. No. Item Description Project No. 4 1 Project Name/Location 2 Owner (Reference) – Contact Info: Name/Address/Telephone/e-mail 3 General Contractor (Contact Name/Address/Telephone/e-mail) 4 Names of JV Partners/Major Subs Performing more than 10% of the Work 5 Roles of JV Partners/Major Subs 6 Names of Project Manager and Superintendents 7 Engineering Firm (Contact Name/Address/Telephone/e-mail) 8 Construction Manager (Contact Name/Address/Telephone/e-mail) Resolution No. 10930 (2018 Series) EXHIBIT APage 49
City of San Luis Obispo Page C-12 Water Resource Recovery Facility Project No. Item Description Project No. 4 9 Description of Project, Scope of Electrical Work Performed 10 Contract Award Date 11 Substantial Completion Date 12 Original Contract Period (calendar days) 13 Actual Construction Time (calendar days) 14 Reason for Delays 15 Electrical Portion of Contract Bid Price 16 Final Electrical Work Portion of Construction Cost (Actual Cost and ENR CCI Adjusted Cost) Basis for Increase or Decrease in Final Electrical Work Construction Cost Resolution No. 10930 (2018 Series) EXHIBIT APage 50
City of San Luis Obispo Page C-13 Water Resource Recovery Facility Project No. Item Description Project No. 4 17 Number of Electrical Work Related Claims Filed (and who filed: Owner or Contractor) 18 Description and % of the Work Self-Performed Supplementary information - please provide any other explanatory notes on the above topics considered relevant on a separate sheet. Resolution No. 10930 (2018 Series) EXHIBIT APage 51
City of San Luis Obispo Page C-14 Water Resource Recovery Facility Project Project Reference 1 of 1 for Part III-B, Question 3: To be considered for pre-qualification, Candidate’s proposed Project Manager (each partner if a joint venture) must have at least ten (10) years of experience managing electrical construction for complex wastewater, recycled water, or potable water treatment facility projects including at least one (1) project with a contract value of $10 million or greater and the proposed Project Manager must have been employed by your firm for at least one (1) year. Candidate (each partner if a joint venture) shall list such projects below. No. Item Description Project No. 5 1 Project Name/Location 2 Owner (Reference) – Contact Info: Name/Address/Telephone/e-mail 3 General Contractor (Contact Name/Address/Telephone/e-mail) 4 Names of JV Partners/Major Subs Performing more than 10% of the Work 5 Roles of JV Partners/Major Subs 6 Names of Project Manager and Superintendents 7 Engineering Firm (Contact Name/Address/Telephone/e-mail) 8 Construction Manager (Contact Name/Address/Telephone/e-mail) Resolution No. 10930 (2018 Series) EXHIBIT APage 52
City of San Luis Obispo Page C-15 Water Resource Recovery Facility Project No. Item Description Project No. 5 9 Treatment Facility: Wastewater, Recycled Water, or Potable Water Total Operating Capacity (million gallons per day - mgd) Treatment Processes 10 Description of Project, Scope of Electrical Work Performed 11 Contract Award Date 12 Substantial Completion Date 13 Original Contract Period (calendar days) 14 Actual Construction Time (calendar days) 15 Reason for Delays 16 Electrical Portion of Contract Bid Price 17 Final Electrical Work Portion of Construction Cost Basis for Increase or Decrease in Final Electrical Work Construction Cost Resolution No. 10930 (2018 Series) EXHIBIT APage 53
City of San Luis Obispo Page C-16 Water Resource Recovery Facility Project No. Item Description Project No. 5 18 Number of Electrical Work Related Claims Filed (and who filed: Owner or Contractor) 19 Description and % of the Work Self-Performed Supplementary information - please provide any other explanatory notes on the above topics considered relevant on a separate sheet. Resolution No. 10930 (2018 Series) EXHIBIT APage 54
City of San Luis Obispo Page C-17 Water Resource Recovery Facility Project Project Reference 1 of 1 for Part III-B, Question 4: To be considered for pre-qualification, Candidate’s (each partner if a joint venture) proposed Project Manager shall have managed the electrical construction of a project that included the installation of medium voltage (1kV to 35 kV) switchgear and medium voltage conductors. Candidate (each partner if a joint venture) shall list such projects below. No. Item Description Project No. 6 1 Project Name/Location 2 Owner (Reference) – Contact Info: Name/Address/Telephone/e-mail 3 General Contractor (Contact Name/Address/Telephone/e-mail) 4 Names of JV Partners/Major Subs Performing more than 10% of the Work 5 Roles of JV Partners/Major Subs 6 Names of Project Manager and Superintendents 7 Engineering Firm (Contact Name/Address/Telephone/e-mail) 8 Construction Manager (Contact Name/Address/Telephone/e-mail) Resolution No. 10930 (2018 Series) EXHIBIT APage 55
City of San Luis Obispo Page C-18 Water Resource Recovery Facility Project No. Item Description Project No. 6 9 Description of Project, Scope of Electrical Work Performed 10 Contract Award Date 11 Substantial Completion Date 12 Original Contract Period (calendar days) 13 Actual Construction Time (calendar days) 14 Reason for Delays 15 Electrical Portion of Contract Bid Price 16 Final Electrical Work Portion of Construction Cost Basis for Increase or Decrease in Final Electrical Work Construction Cost Resolution No. 10930 (2018 Series) EXHIBIT APage 56
City of San Luis Obispo Page C-19 Water Resource Recovery Facility Project No. Item Description Project No. 6 17 Number of Electrical Work Related Claims Filed (and who filed: Owner or Contractor) 18 Description and % of the Work Self-Performed Supplementary information - please provide any other explanatory notes on the above topics considered relevant on a separate sheet. Resolution No. 10930 (2018 Series) EXHIBIT APage 57
City of San Luis Obispo Page C-20 Water Resource Recovery Facility Project Project Reference 1 of 1 for Part III-B, Question 5: To be considered for pre-qualification, Candidate’s proposed Superintendent (each partner if a joint venture) must have at least seven (7) years of experience managing electrical construction for complex treatment facility projects (wastewater, recycled water, or potable water) including at least one (1) project with a contract value of $10 million or greater and the proposed Superintendent must have been employed by your firm for at least one (1) year. Candidate (each partner if a joint venture) shall list such projects below. No. Item Description Project No. 7 1 Project Name/Location 2 Owner (Reference) – Contact Info: Name/Address/Telephone/e-mail 3 General Contractor (Contact Name/Address/Telephone/e-mail) 4 Names of JV Partners/Major Subs Performing more than 10% of the Work 5 Roles of JV Partners/Major Subs 6 Names of Project Manager and Superintendents 7 Engineering Firm (Contact Name/Address/Telephone/e-mail) 8 Construction Manager (Contact Name/Address/Telephone/e-mail) Resolution No. 10930 (2018 Series) EXHIBIT APage 58
City of San Luis Obispo Page C-21 Water Resource Recovery Facility Project No. Item Description Project No. 7 9 Treatment Facility: Wastewater, Recycled Water, or Potable Water Total Operating Capacity (million gallons per day - mgd) Treatment Processes 10 Description of Project, Scope of Electrical Work Performed 11 Contract Award Date 12 Substantial Completion Date 13 Original Contract Period (calendar days) 14 Actual Construction Time (calendar days) 15 Reason for Delays 16 Electrical Portion of Contract Bid Price 17 Final Electrical Work Portion of Construction Cost Basis for Increase or Decrease in Final Electrical Work Construction Cost Resolution No. 10930 (2018 Series) EXHIBIT APage 59
City of San Luis Obispo Page C-22 Water Resource Recovery Facility Project No. Item Description Project No. 7 18 Number of Electrical Work Related Claims Filed (and who filed: Owner or Contractor) 19 Lost Time Accident Frequency Rate1 20 Description and % of the Work Self-Performed Supplementary information - please provide any other explanatory notes on the above topics considered relevant on a separate sheet. 1 Lost Time Frequency Rate = Number of Lost Time Accidents x 100,000/Labor Hours Worked. Resolution No. 10930 (2018 Series) EXHIBIT APage 60
City of San Luis Obispo Page D-1 Water Resource Recovery Facility Project
APPENDIX D
Release and Waiver Agreement
RFQ: Electrical Subcontractors for
Construction of the Water Resource Recovery Facility Project
This Release and Waiver of Liability (hereinafter the “Release”) is entered into between
the City of San Luis Obispo, and
_______________________________________________________________ , a “Candidate.”
RECITALS
1. The City of San Luis Obispo ("City”) has issued a Request for Qualifications to establish
a pool of Candidates qualified to perform electrical work for the Water Resource
Recovery Facility Project.
2. Candidate has submitted a response to the City’s Request for Qualifications and has
listed projects and owners as references for its qualifications.
3. The City seeks candid comments on the Candidate’s performance on the listed projects
from the owners and the owners’ representatives.
RELEASE AND WAIVER
Candidate hereby fully and forever releases, exonerates, discharges, and covenants not
to sue the City, its officers and employees, its consultants and subconsultants, and all individuals
and entities furnishing comments on Candidate’s performance, from and does hereby waive, any
and all claims, causes of action, demands, damages and any and all other liabilities of any kind
or description, in law, equity, or otherwise, arising out of information furnished about Candidate’s
performance on the projects Candidate has identified pursuant to Recital number 2, hereinabove.
INTENDED BENEFICIARIES
The City, its officers and employees and all individuals and entities furnishing any
information relating to Candidate’s qualifications are intended beneficiaries of this Release and
Waiver and are entitled to enforce its terms.
Candidate
Authorized Representative
Date
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 61
City of San Luis Obispo Page E-1 Water Resource Recovery Facility Project
APPENDIX E
Project Reference Questionnaire
RFQ: Electrical Subcontractors for Construction of the
Water Resource Recovery Facility Project
THIS PAGE PROVIDED FOR INFORMATIONAL PURPOSES ONLY
The City of San Luis Obispo (“City”) is undertaking a process to prequalify electrical
subcontractors ("Candidates") for construction of the Water Resource Recovery Facility (WRRF)
Project.
The following Candidate, _____________________________________, has provided the City
with the name of your organization and the following project: ____________________________
as references regarding the Candidate’s experience and qualifications to perform Work on the
WRRF Project. The Candidate has signed a Release and Waiver of Liability form as to the
information you provide, a copy of which is attached for your reference.
Please complete and return the questionnaire to City’s Program Manager:
Name: Justin Pickard, Water Systems Consulting, Inc.
Email Address: jpickard@wsc-inc.com
Please give a brief description of the project; be sure to include the value of the project, the type of
contract utilized, and the scope of work involved.
1. On a scale of 1-5, with 5 being the best, did the Candidate respond in a
timely and responsible manner to stop notices or liens on the project?
(Max. 5 points) ____ / 5 pts
2. On a scale of 1-10, with 10 being the best, did the Candidate provide
adequate project management personnel to administer the contract in
accordance with the contract documents? (Max. 10 points) ____ / 10 pts
3. On a scale of 1-10, with 10 being the best, did the Candidate provide
adequate field personnel to construct the electrical work in accordance with
the contract documents? (Max. 10 points) ____ / 10 pts
4. On a scale of 1-10, with 10 being the best, did the Candidate provide
adequate supervision of the electrical portion of the work? (Max. 10 points) ____ / 10 pts
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 62
City of San Luis Obispo Page E-2 Water Resource Recovery Facility Project
5. On a scale of 1-5, with 5 being the best, was there adequate equipment
provided on the job to meet the contract schedule? (Max. 5 points) ____ / 5 pts
6. On a scale of 1-10, with 10 being the best, was the Candidate timely in
providing reports and other paperwork, including submittals, certified
payroll reports, change order paperwork, and monthly schedule updates?
(Max. 10 points) ____ / 10 pts
7. On a scale of 1-10, with 10 being the best, did the Candidate adhere to the
project schedule that your agency approved? (Max. 10 points) ____ / 10 pts
8. Was the electrical portion of the project completed within the contract time
originally set forth in the bid documents? (10 points if the answer is “Yes”).
Or, if the answer is “no,” on a scale of 1-10, with 10 being not responsible
and 1 being fully responsible, to what extent was the Candidate
responsible for the delay in completion? (Max. 10 points)
____/10 pts
9. On a scale of 1-10, with 10 being the best, rate the contractor on the timely
submission of reasonable cost and time estimates to perform change order
work. (Max. 10 points) ____ / 10 pts
10. On a scale of 1-10, with 10 being the best, rate the Candidate on how well
the contractor performed the work after a change order was issued, and
how well the contractor integrated the change order work into the existing
work. (Max. 10 points) ____ / 10 pts
11. On a scale of 1-10, with 10 being the best, rate the Candidate’s
performance in regard to timely submittal of operation & maintenance
manuals, maintaining and completing as-built drawings, providing required
training and taking care of warranty items? (Max. 10 points) ____ / 10 pts
12. On a scale of 1-10, with 10 being the best, rate the Candidate on whether
there were an unusually high number of contractor-initiated change orders,
claims, and disputes given the nature of the project, or unusual difficulty in
resolving them. (Max. 10 points) ____ / 10 pts
13. On a scale of 1-10, with 10 being the highest, rate the Candidate with
respect to timely payments by the contractor to either subcontractors or
suppliers. (If the person being interviewed knows of no such difficulties, the
score on this question should be “10”.) (Max. 10 points)
____/10 pts
14. On a scale of 1-15, with 15 being the best, how would you rate the overall
quality of the Candidate’s work? (Max. 15 points) ____/15 pts
15. On a scale of 1-15, with 15 being the best, how would you rate the
Candidate’s ability to maintain operation of the existing facilities during the
course of the improvements through advance planning, coordination with
the owner, preparation of maintenance of plant operation (MOPO)
submittals, and proper execution of the work? (If the improvements were
not constructed in an existing facility that remained in operation during
construction, the score on this question should be “15”.) (Max 15 points)
____/15 pts
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 63
City of San Luis Obispo Page E-3 Water Resource Recovery Facility Project
16. On a scale of 1-15, with 15 being the best, how would you rate the
Candidate’s ability to prepare a comprehensive startup and commissioning
plan for the project in a timely manner and to successfully start-up the
facility within a reasonable amount of time? (Max. 15 points) ____/15 pts
17. On a scale of 1-10, with 10 being the best, rate the contractor with respect
to compliance with safety requirements established by law and best
industry practice, including but not limited to: was shoring provided
properly, were lock-out/tag-out procedures followed, did the contractor
provide routine safety training? (Max. 10 points) ____/10 pts
To Be Completed by Person Providing Reference:
Reference is provided by: ____________________________________________________
Job Title: _________________________________________________________________
Date: ____________________________________________________________________
Company/Agency: __________________________________________________________
Business Address; __________________________________________________________
Telephone Number: ________________________________________________________
E-Mail Address: ____________________________________________________________
Relationship to Referenced Contract/Project: _____________________________________
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 64
City of San Luis Obispo Page F-1 Water Resource Recovery Facility Project
APPENDIX F
Affidavit
We, the undersigned, (name) as the authorized
representatives for (company) an interested
contractor for the City of San Luis Obispo’s (City) Water Resource Recovery Facility Project
(Project ) Bidders List, do hereby attest that all statements and representations made herein are
true and correct to the best of our knowledge. These statements are made openly and freely
without intent to influence or embellish actual conditions or circumstances that occurred. I declare
under penalty of perjury under the laws of the State of California that the foregoing is correct.
We acknowledge that we have received Addendum through .
We understand that the City will investigate any and all statements and representations made by
us and our firm in this Statement of Qualifications and we freely give our permission for them to
do so. Should releases be required by any of our professional, financial, or bonding institutions to
release verification of the enclosed data, we have provided them. We agree to waive any claims
against the City, Construction Manager, Design Engineer and/or any third party designated by
the City for the release of the information necessary to evaluate this Statement of Qualifications.
We further understand that any false statement or representations made in this application will
result in disqualification of our firm as a bidder for the Project. If it is determined that these false
statements or representations were purposefully made to change, hide, or obscure negative
information from City in an attempt to qualify under these false pretenses, the action will result in
loss of eligibility for our firm to qualify for any City contracts for a minimum period of one (1) year
and a maximum period of five (5) years from the date of discovery.
(Name)
(Signature)
(Title)
Attested: Corporate Seal
(Name)
(Signature)
(Title)
Date , 2018
END OF AFFIDAVIT
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 65
City of San Luis Obispo G-1 Water Resource Recovery Facility Project
APPENDIX G
Key Personnel Data Sheet
RFQ: Electrical Subcontractors for Construction of the
Water Resource Recovery Facility Project
The following information shall be submitted for each person listed below (additional pages shall
be attached and properly designated if necessary).
1. Project Manager
2. All Contract Superintendent positions
Name
Position Title
Education/Qualifications:
Present Position with Contractor or Subcontractor:
_____________________________________________________________________________
Number of Years of Experience in Present/Proposed Position:
Number of Years with Company in Present/Proposed Position:
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 66
City of San Luis Obispo G-2 Water Resource Recovery Facility Project
Relevant Experience (List project name, scope of work, start and end dates of person’s participation
with the work, and position key personnel held during project, for the last three relevant projects):
_____________________________________________________________________________
_____________________________________________________________________________
_____________________________________________________________________________
Employment History (within past 10 years):
_____________________________________________________________________________
_____________________________________________________________________________
_____________________________________________________________________________
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 67
City of San Luis Obispo H-1 Water Resource Recovery Facility Project
APPENDIX H
City Minimum Insurance Requirements
(Subject to Revision in Accordance with the Contract Documents)
Prior to the beginning of and throughout the duration of the Project, Contractor and its
subcontractors shall maintain insurance in conformance with the requirements set forth below.
Contractor will use existing coverage to comply with these requirements. If that existing coverage
does not meet the requirements set forth herein, Contractor agrees to amend, supplement or
endorse the existing coverage to do so. If Contractor’s existing coverage exceeds the coverage
limits set forth herein, then those higher limits shall apply.
Contractor acknowledges that the insurance coverage and policy limits set forth in this section
constitute the minimum amount of coverage required. Any insurance proceeds available to
Contractor or its subcontractors in excess of the limits and coverage identified in this Agreement
and which is applicable to a given loss, claim or demand, will be equally available to City.
A. Contractor shall provide the following types and amounts of insurance:
Without limiting Contractor’s indemnification of City, and prior to commencement of the Project,
Contractor shall obtain, provide and maintain at its own expense during the term of this
Agreement, policies of insurance of the type and amounts described below and in a form
satisfactory to City.
General Liability Insurance. Contractor shall maintain commercial general liability insurance
with coverage at least as broad as Insurance Services Office form CG 00 01, in an amount not
less than $25,000,000 per occurrence, $35,000,000 general aggregate, for bodily injury, personal
injury, and property damage, and a $35,000,000 completed operations aggregate. The policy
must include contractual liability that has not been amended. Any endorsement restricting
standard ISO “insured contract” language will not be accepted.
Automobile Liability Insurance. Contractor shall maintain automobile insurance at least as
broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage
for all activities of the Contractor arising out of or in connection with Work to be performed under
this Agreement, including coverage for any owned, hired, non-owned or rented vehicles, in an
amount not less than $5,000,000 combined single limit for each accident.
Umbrella or Excess Liability Insurance. Contractor shall obtain and maintain an umbrella or
excess liability insurance that will provide bodily injury, personal injury and property damage
liability coverage at least as broad as the primary coverages set forth above, including commercial
general liability, automobile liability, and employer’s liability. Such policy or policies shall include
the following terms and conditions:
A drop-down feature requiring the policy to respond in the event that any primary insurance
that would otherwise have applied proves to be uncollectable in whole or in part for any
reason;
Pay on behalf of wording as opposed to reimbursement;
Concurrency of effective dates with primary policies;
Policies shall “follow form” to the underlying primary policies; and
Insureds under primary policies shall also be insureds under the umbrella or excess
policies.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 68
City of San Luis Obispo H-2 Water Resource Recovery Facility Project
Workers’ Compensation Insurance. Contractor shall maintain Workers’ Compensation
Insurance (Statutory Limits) and Employer’s Liability Insurance (with limits of at least $1,000,000)
for Contractor’s employees in accordance with the laws of the State of California, Section 3700
of the Labor Code. In addition, Contractor shall require each subcontractor to similarly maintain
Workers’ Compensation Insurance and Employer’s Liability Insurance in accordance with the laws
of the State of California, Section 3700 for all of the subcontractor’s employees.
Contractor shall submit to City, along with the certificate of insurance, a Waiver of Subrogation
endorsement in favor of City, its officers, agents, employees and volunteers.
Pollution Liability Insurance. Environmental Impairment Liability Insurance shall be written on
a Contractor’s Pollution Liability form or other form acceptable to City providing coverage for
liability arising out of sudden, accidental and gradual pollution and remediation. The policy limit
shall be no less than $1,000,000 dollars per claim and in the aggregate. All activities contemplated
in this Agreement shall be specifically scheduled on the policy as “covered operations.” The policy
shall provide coverage for the hauling of waste from the project site to the final disposal location,
including non-owned disposal sites.
Contractor’s Equipment Insurance. Contractors’ equipment insurance sufficient to cover the
physical damage to all owned, leased, rented, or borrowed equipment used on the jobsite,
including rental charges. All contractors’ miscellaneous tools shall be covered by the individual
contractor or Subcontractor.
Builder’s Risk Insurance. Upon commencement of construction and with approval of City,
Contractor shall obtain and maintain builder’s risk insurance for the entire duration of the Project
until only the City has an insurable interest. The Builder’s Risk coverage shall include the
coverages as specified below.
The named insureds shall be Contractor and City, including its officers, officials, employees, and
agents. All Subcontractors (excluding those solely responsible for design Work) of any tier and
suppliers shall be included as additional insureds as their interests may appear. Contractor shall
not be required to maintain property insurance for any portion of the Project following transfer of
control thereof to City. The policy shall contain a provision that all proceeds from the builder’s risk
policy shall be made payable to the City. The City will act as a fiduciary for all other interests in
the Project.
Policy shall be provided for replacement value on an "all risk" basis for the completed value of the
project. There shall be no coinsurance penalty or provisional limit provision in any such policy.
Policy must include: (1) coverage for any ensuing loss from faulty workmanship, Nonconforming
Work, omission or deficiency in design or specifications; (2) coverage against machinery
accidents and operational testing; (3) coverage for removal of debris, and insuring the buildings,
structures, machinery, equipment, materials, facilities, fixtures and all other properties constituting
a part of the Project; (4) Ordinance or law coverage for contingent rebuilding, demolition, and
increased costs of construction; (5) transit coverage (unless insured by the supplier or receiving
contractor), with sub-limits sufficient to insure the full replacement value of any key equipment
item; (6) Ocean marine cargo coverage insuring any Project materials or supplies, if applicable;
(7) coverage with sub-limits sufficient to insure the full replacement value of any property or
equipment stored either on or off the Site or any staging area. Such insurance shall be on a form
acceptable to City to ensure adequacy of terms and sublimits and shall be submitted to the City
prior to commencement of construction.
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 69
City of San Luis Obispo H-3 Water Resource Recovery Facility Project
OTHER PROVISIONS OR REQUIREMENTS
Proof of Insurance. Contractor shall provide certificates of insurance to City as evidence of the
insurance coverage required herein, along with a waiver of subrogation endorsement for workers’
compensation. Insurance certificates and endorsements must be approved by City’s risk manager
prior to commencement of performance. Current certification of insurance shall be kept on file
with City at all times during the term of this contract. City reserves the right to require complete,
certified copies of all required insurance policies, at any time.
Duration of Coverage. Contractor shall procure and maintain for the duration of the contract
insurance against claims for injuries to persons or damages to property, which may arise from or
in connection with the performance of the Work hereunder by Contractor, his agents,
representatives, employees or subcontractors. Contractor must maintain general liability and
umbrella or excess liability insurance for as long as there is a statutory exposure to completed
operations claims. City and its officers, officials, employees, and agents shall continue as
additional insureds under such policies.
Primary/Noncontributing. Coverage provided by Contractor shall be primary and any insurance
or self-insurance procured or maintained by City shall not be required to contribute with it. The
limits of insurance required herein may be satisfied by a combination of primary and umbrella or
excess insurance. Any umbrella or excess insurance shall contain or be endorsed to contain a
provision that such coverage shall also apply on a primary and non-contributory basis for the
benefit of City before the City’s own insurance or self-insurance shall be called upon to protect it
as a named insured.
Products/Completed Operations Coverage. Products/completed operations coverage shall
extend a minimum of ten (10) years after project completion. Coverage shall be included on behalf
of the insured for covered claims arising out of the actions of independent contractors. If the
insured is using subcontractors, the Policy must include work performed “by or on behalf” of the
insured. Policy shall contain no language that would invalidate or remove the insurer’s duty to
defend or indemnify for claims or suits expressly excluded from coverage. Policy shall specifically
provide for a duty to defend on the part of the insurer. The City, its officials, officers, agents, and
employees, shall be included as additional insureds under the Products and Completed
Operations coverage.
Agency’s Rights of Enforcement. In the event any policy of insurance required under this
Agreement does not comply with these requirements or is canceled and not replaced, City has
the right but not the duty to obtain the insurance it deems necessary and any premium paid by
City will be promptly reimbursed by Contractor or City will withhold amounts sufficient to pay
premium from Contractor payments. In the alternative, City may cancel this Agreement.
Acceptable Insurers. All insurance policies shall be issued by an insurance company currently
authorized by the Insurance Commissioner to transact business of insurance or is on the List of
Approved Surplus Line Insurers in the State of California, with an assigned policyholders’ Rating
of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest
edition of Best’s Key Rating Guide, unless otherwise approved by the City’s risk manager.
Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this
agreement shall be endorsed to waive subrogation against City, its elected or appointed officers,
agents, officials, employees and volunteers or shall specifically allow Contractor or others
providing insurance evidence in compliance with these specifications to waive their right of
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 70
City of San Luis Obispo H-4 Water Resource Recovery Facility Project
recovery prior to a loss. Contractor hereby waives its own right of recovery against City, and shall
require similar written express waivers and insurance clauses from each of its subconsultants.
Enforcement of contract provisions (non estoppel). Contractor acknowledges and agrees that
any actual or alleged failure on the part of the City to inform Contractor of non-compliance with
any requirement imposes no additional obligations on the City nor does it waive any rights
hereunder.
Requirements not Limiting. Requirements of specific coverage features or limits contained in
this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver
of any coverage normally provided by any insurance. Specific reference to a given coverage
feature is for purposes of clarification only as it pertains to a given issue and is not intended by
any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any
type. If the Contractor maintains higher limits than the minimums shown above, the City requires
and shall be entitled to coverage for the higher limits maintained by the Contractor. Any available
insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be
available to the City.
Notice of Cancellation. Contractor agrees to oblige its insurance agent or broker and insurers
to provide to City with a thirty (30) day notice of cancellation (except for nonpayment for which a
ten (10) day notice is required) or nonrenewal of coverage for each required coverage.
Additional Insured Status. General liability policies shall provide or be endorsed to provide that
AGENCY and its officers, officials, employees, agents, and volunteers shall be additional insureds
under such policies. This provision shall also apply to any excess/umbrella liability policies.
Prohibition of undisclosed coverage limitations. None of the coverages required herein will
be in compliance with these requirements if they include any limiting endorsement of any kind
that has not been first submitted to City and approved of in writing.
Separation of Insureds. A severability of interests provision must apply for all additional insureds
ensuring that Contractor’s insurance shall apply separately to each insured against whom claim
is made or suit is brought, except with respect to the insurer’s limits of liability. The policy(ies)
shall not contain any cross-liability exclusions.
Pass Through Clause. Contractor agrees to ensure that its subconsultants, subcontractors, and
any other party involved with the project who is brought onto or involved in the project by
Contractor, provide the same minimum insurance coverage and endorsements required of
Contractor. Contractor agrees to monitor and review all such coverage and assumes all
responsibility for ensuring that such coverage is provided in conformity with the requirements of
this section. Contractor agrees that upon request, all agreements with consultants,
subcontractors, and others engaged in the project will be submitted to City for review.
Agency’s Right to Revise Requirements. The City reserves the right at any time during the
term of the contract to change the amounts and types of insurance required by giving the
Contractor a ninety (90) day advance written notice of such change. If such change results in
substantial additional cost to the Contractor, the City and Contractor may renegotiate Contractor’s
compensation.
Self-insured Retentions. Any self-insured retentions must be declared to and approved by City.
City reserves the right to require that self-insured retentions be eliminated, lowered, or replaced
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 71
City of San Luis Obispo H-5 Water Resource Recovery Facility Project
by a deductible. Self-insurance will not be considered to comply with these specifications unless
approved by City.
Timely Notice of Claims. Contractor shall give City prompt and timely notice of claims made or
suits instituted that arise out of or result from Contractor’s performance under this Agreement,
and that involve or may involve coverage under any of the required liability policies.
Additional Insurance. Contractor shall also procure and maintain, at its own cost and expense,
any additional kinds of insurance, which in its own judgment may be necessary for its proper
protection and prosecution of the Work.
END OF INSURANCE REQUIREMENTS
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 72
City of San Luis Obispo I-1 Water Resource Recovery Facility Project
APPENDIX I
Certification of Surety
(To be submitted on bonding agency letterhead)
THIS PAGE PROVIDED FOR INFORMATIONAL PURPOSES ONLY
Date:
To: City of San Luis Obispo
XXXX
XXXX
Attn: XXXX
Re: RFQ Electrical Subcontractors for Construction of the Water Resource
Recovery Facility Project
Name of
Contractor:
City/State:
is authorized to execute bid, performance,
(Name of Bonding Agency)
and payment bonds for the above named contractor subject to the following conditions:
1. Contract price of any one contract does not exceed $ .
2. Total amount of uncompleted work on hand, both bonded and unbonded, does
not exceed $ .
3. This work authority expires June 30, _____ unless previously rescinded in
writing. Written notice of rescission will be provided to the above addressee
within seven days of such rescission.
Signed by:
(Authorized Bonding Agency Representative)
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 73
City of San Luis Obispo I-2 Water Resource Recovery Facility Project
Candidate Name:_____________________________________ Date:_________________
Email: ______________________________________________
Subscribed and sworn to before me
this day of , 20
Notary Public in and for the State of:
Residing at:
Expiration Date:
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 74
City of San Luis Obispo J-1 Water Resource Recovery Facility Project
APPENDIX J
Scoring Instructions
The scorable questions are in three different parts of the Prequalification Questionnaire:
Part II(B)-(F) History of the business and organizational performance
Part II(G)-(H) Compliance with occupational safety and health laws, workers’
compensation and other labor legislation
Part III Mandatory Project Experience
PART II SCORING INSTRUCTIONS
B. Questions about History of the Business and Organizational Performance
6. How many years has the Candidate’s organization been in business in California as a
contractor under the Candidate’s present business name and license number?
0 – 5 years = 0 points
5 – 9 years or more = 2 points
9 – 12 years = 3 points
12 – 15 years = 4 points
15 years or more = 5 points
7. Is the Candidate currently the debtor in a bankruptcy case?
Yes No
If “yes,” please attach a copy of the bankruptcy petition, showing the case number, and
the date on which the petition was filed.
“No” = 3 points “Yes” = 0 points
8. Was the Candidate in bankruptcy at any time during the last five years? This question
refers only to a bankruptcy action that was not described in answer to question 7, above.
Yes No
If “yes,” please attach a copy of the bankruptcy petition, showing the case number and the
date on which the petition was filed, and a copy of the Bankruptcy Court’s discharge order,
or of any other document that ended the case, if no discharge order was issued.
“No” = 3 points “Yes” = 0 points
C. Licenses
13. Has any CSLB license held by the Candidate or its Responsible Managing Employee
(RME) or Responsible Managing Officer (RMO) been suspended or revoked within the
last five (5) years?
Yes No
“No” = 5 points “Yes” = 0 points
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 75
City of San Luis Obispo J-2 Water Resource Recovery Facility Project
D. Disputes
14. At any time in the last five (5) years, has the Candidate been assessed liquidated damages
after completion of a project, under a construction contract with either a public or private
owner?
Yes No
No projects with liquidated damages of more than $50,000 = 5 points
Only one project with liquidated damages of more than $50,000 = 2 points
Any other answer = 0 points
15. In the last five (5) years, has the Candidate been denied an award of a public works
contract based on a finding by a public agency that the Candidate’s company was not a
responsible bidder?
Yes No
“No” = 5 points “Yes” = 0 points
16. In the past five (5) years, has any claim against the Candidate concerning the Candidate’s
performance of a construction project, been filed in court or arbitration?
Yes No
5 points for either “No” or “Yes” indicating 1 such instance
3 points for “Yes” indicating 2 such instances
0 points for “Yes” if more than 2 such instances
17. In the past five (5) years, has the Candidate made any claim against a project owner
concerning work on a project or payment for a contract, and filed that claim in court or
arbitration?
Yes No
5 points for either “No” or “Yes” indicating 1 such instance
3 points for “Yes” indicating 2 such instances
0 points for “Yes” if indicating more than 2 such instances
18. At any time during the past five (5) years, has any surety company made any payments
on the Candidate’s behalf, to satisfy any claims made against a performance or payment
bond issued on the Candidate’s behalf in connection with a construction project, either
public or private?
Yes No
5 points for “No”
3 points for “Yes” indicating no more than 1 such claim
Subtract five points for “Yes” indicating more than 1 such claim
19. In the last five (5) years, has any insurance carrier, for any form of insurance, refused to
renew the insurance policy for the Candidate?
Yes No
5 points for either “No” or “Yes” indicating 1 such instance
3 points for “Yes” indicating 2 such instances
0 points for “Yes” or if more than 2 such instances
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 76
City of San Luis Obispo J-3 Water Resource Recovery Facility Project
E. Criminal Matters and Related Civil Suits
20. Has the Candidate, or any of its owners, officers or partners ever been convicted of a
crime involving any federal, state, or local law related to construction?
Yes No
“No” = 5 points “Yes” = subtract 5 points
21. Has the Candidate or any of its owners, officers or partners ever been convicted of a
federal or state crime of fraud, theft, or any other act of dishonesty?
Yes No
“No” = 5 points “Yes” = subtract 5 points
F. Bonding
23. If the Candidate was required to pay a premium of more than one (1) percent for a
performance and payment bond on any project(s) on which the Candidate worked at any
time during the last five (5) years, state the percentage that the Candidate was required
to pay. The Candidate may provide an explanation for a percentage rate higher than one
(1) percent, if the Candidate wishes to do so.
__________________%
5 points if the rate is less than or equal to 1.1 percent
3 points if the rate is greater than 1.1 percent but less than or equal to 1.2 percent
0 points for any other answer
25. During the last five (5) years, has the Candidate ever been denied bond credit by a surety
company, or has there ever been a period of time when the Candidate had no surety bond
in place during a public construction project when one was required?
Yes No
“No” = 5 points “Yes” = 0 points
G. Questions about compliance with safety, workers compensation, prevailing wage
and apprenticeship laws.
26. Has CAL OSHA cited and assessed penalties against the Candidate for any “serious”,
“willful” or “repeat” violations of its safety or health regulations in the past five (5) years?
Yes No
5 points for either “No” or “Yes” indicating 1 such instance
3 points for “Yes” indicating 2 such instances
0 points for “Yes” indicating more than 2 such instances
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 77
City of San Luis Obispo J-4 Water Resource Recovery Facility Project
27. Has the federal Occupational Safety and Health Administration cited and assessed
penalties against the Candidate in the past five (5) years?
Yes No
If yes, attach a separate signed page describing each citation.
5 points for either “No” or “Yes” indicating 1 such instance
3 points for “Yes” indicating 2 such instances
0 points for “Yes” indicating more than 2 such instances
28. As a result of the Candidate’s company’s actions or inactions, has the EPA or any Air
Quality Management District or any Regional Water Quality Control Board cited and
assessed penalties against either the Candidate or the owner of a project on which the
Candidate was the contractor, in the past five (5) years?
Yes No
5 points for either “No” or “Yes” indicating 1 such instance
3 points for “Yes” indicating 2 such instances
0 points for “Yes” indicating more than 2 such instances
29. How often does the Candidate require documented safety meetings to be held for
construction employees and field supervisors during the course of a project?
3 points for an answer of once each week or more often
0 points for any other answer
30. Experience Modification Rate (EMR): Please obtain a letter from the Candidate’s
insurance carrier (or state fund if applicable) with the Candidate’s interstate EMR’s for the
last three (3) years. If the Candidate does not have an interstate rating, obtain the
Candidate’s intrastate EMR’s. Attach the letter as part of this package. The Candidate
shall list the Experience Modification Rate for the last three (3) years (available from the
Candidate’s insurance carrier).
Year EMR
Three Year Average =
Are the above rates interstate or intrastate? ____________________
NOTE: Any of the following methods of “obtaining a letter” are acceptable:
(1) Furnish a letter from the Candidate’s insurance agent, insurance carrier or
state fund (on their letterhead) verifying the EMR data listed above; or
(2) Furnish a photocopy of the applicable Experience Rating Calculation
Sheets, which the Candidate’s insurance carrier should forward to the
Candidate annually.
5 points for three-year average EMR of 0.75 or less
3 points for three-year average of EMR of more than 0.75 but no more than 1.00
0 points for any other EMR
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 78
City of San Luis Obispo J-5 Water Resource Recovery Facility Project
31. Within the last five (5) years, has there ever been a period when the Candidate had
employees but was without workers’ compensation insurance or state-approved self-
insurance?
Yes No
5 points for either “No” or “Yes” indicating 1 such instance
0 points for any other answer
H. Prevailing Wage and Apprenticeship Compliance Record
32. Has the Candidate been required at any time during the last five (5) years to pay either
back wages or penalties for the Candidate’s own firm’s failure to comply with the
California’s prevailing wage laws?
Yes No
NOTE: This question refers only to the Candidate’s own firm’s violation of
prevailing wage laws, not to violations of the prevailing wage laws by a
subcontractor.
5 points for “No”
3 points for “Yes” indicating 1 or 2 such instances
0 points for “Yes” indicating more than 2 such instances
33. During the last five (5) years, has the Candidate’s own firm has been penalized or required
to pay back wages for failure to comply with the federal Davis-Bacon prevailing wage
requirements?
Yes No
5 points for “No”
3 points for “Yes” indicating 1 or 2 such instances
0 points for “Yes” indicating more than 2 such instances
34. At any time during the last five (5) years, has the Candidate been found to have violated
any provision of California apprenticeship laws or regulations, or the laws pertaining to
use of apprentices on public works?
NOTE: The Candidate may omit reference to any incident that occurred if the
violation was by a subcontractor and the Candidate, as general contractor on a
project, had no knowledge of the subcontractor’s violation at the time they
occurred.
Yes No
If yes, provide the date(s) of such findings, and attach copies of the Department’s final
decision(s).
5 points for “No”
3 points for “Yes” indicating 1 or 2 such instances
0 points for “Yes” indicating more than 2 such instances
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 79
City of San Luis Obispo J-6 Water Resource Recovery Facility Project
PART III SCORING WORKSHEET
Question Score
1. On a scale of 1-5, with 5 being the best, did the Candidate respond in a timely
and responsible manner to stop notices or liens on the project? (Max. 5 points)
2. On a scale of 1-10, with 10 being the best, did the Candidate provide
adequate project management personnel to administer the contract in
accordance with the contract documents? (Max. 10 points)
3. On a scale of 1-10, with 10 being the best, did the Candidate provide
adequate field personnel to construct the work in accordance with the contract
documents? (Max. 10 points)
4. On a scale of 1-10, with 10 being the best, did the Candidate provide
adequate supervision of the work? (Max. 10 points)
5. On a scale of 1-5, with 5 being the best, was there adequate equipment
provided on the job to meet the contract schedule? (Max. 5 points)
6. On a scale of 1-10, with 10 being the best, was the Candidate timely in
providing reports and other paperwork, including submittals, certified payroll
reports, change order paperwork, and monthly schedule updates? (Max. 10
points)
7. On a scale of 1-10, with 10 being the best, did the Candidate adhere to the
project schedule that your agency approved? (Max. 10 points)
8. Was the project completed within the contract time originally set forth in the
bid documents? (10 points if the answer is “Yes”). Or, if the answer is “no,” on
a scale of 1-10, with 10 being not responsible and 1 being fully responsible,
to what extent was the Candidate responsible for the delay in completion?
(Max. 10 points)
9. On a scale of 1-10, with 10 being the best, rate the Candidate on the timely
submission of reasonable cost and time estimates to perform change order
work. (Max. 10 points)
10. On a scale of 1-10, with 10 being the best, rate the Candidate on how well the
Candidate performed the work after a change order was issued, and how well
the Candidate integrated the change order work into the existing work. (Max.
10 points)
11. On a scale of 1-10, with 10 being the best, rate the Candidate’s performance
in regard to timely submittal of operation & maintenance manuals, maintaining
and completing as-built drawings, providing required training and taking care
of warranty items? (Max. 10 points)
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 80
City of San Luis Obispo J-7 Water Resource Recovery Facility Project
12. On a scale of 1-10, with 10 being the best, rate the Candidate on whether
there were an unusually high number of Candidate-initiated change orders,
claims, and disputes given the nature of the project, or unusual difficulty in
resolving them. (Max. 10 points)
13. On a scale of 1-10, with 10 being the highest, rate the Candidate with
respect to timely payments by the Candidate to either subcontractors or
suppliers. (If the person being interviewed knows of no such difficulties, the
score on this question should be “10”.) (Max. 10 points)
14. On a scale of 1-15, with 15 being the best, how would you rate the overall
quality of the Candidate’s work? (Max. 15 points)
15. On a scale of 1-15, with 15 being the best, how would you rate the
Candidate’s ability to maintain operation of the existing facilities during the
course of the improvements through advance planning, coordination with the
owner, preparation of maintenance of plant operation (MOPO) submittals,
and proper execution of the work? (If the improvements were not
constructed in an existing facility that remained in operation during
construction, the score on this question should be “15”.) (Max. 15 points)
16. On a scale of 1-15, with 15 being the best, how would you rate the
Candidate’s ability to prepare a comprehensive startup and commissioning
plan for the project in a timely manner and to successfully start-up the facility
within a reasonable amount of time? (Max. 15 points)
17. On a scale of 1-10, with 10 being the best, rate the Candidate with respect
to compliance with safety requirements established by law and best industry
practice, including but not limited to: was shoring provided properly, were
lock-out/tag-out procedures followed, did the Candidate provide routine
safety training? (Max. 10 points)
TOTAL
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 81
City of San Luis Obispo K-1 Water Resource Recovery Facility Project
APPENDIX K
CITY OF SAN LUIS OBISPO
PREQUALIFICATION OF ELECTRICAL SUBCONTRACTORS
FOR THE
WATER RESOURCE RECOVERY FACILITY PROJECT
Prequalification Evaluation
Candidate Name:
Evaluation Criteria
Maximum
Points
Available
Required Score Actual Score
Part I: Essential Requirements Pass Pass Pass/Fail
(circle one)
Part II: B - F History of Business and
Organizational Performance
66 points 50 points
G - H Safety, Prevailing Wage and
Apprenticeship
43 points 31 points
Part III Mandatory Project Experience 175 points
(per project)
122 points
(each project)
Pass/Fail
(circle one)
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 82
City of San Luis Obispo L-1 Water Resource Recovery Facility Project
APPENDIX L
Reference Drawings
RFQ: Electrical Subcontractors for Construction of the Water Resource Recovery
Facility Project
The following preliminary construction drawings attached hereto are preliminary for reference
only and are not for bidding purposes.
ID Sheet No. Sheet Title
1 01-G-0001 Title, Vicinity and Location Maps
2 01-G-0041 Process Flow Diagram Liquids and Solids 1
3 01-G-0042 Process Flow Diagram Liquids and Solids 2
4 01-G-0043 Hydraulic Profile 1
5 01-G-0043A Hydraulic Profile 2
6 05-XF-1000 Overall Site Facility and Piping Demolition Plan
7 05-C-1000 Overall Key Plan
8 05-CG-1000 Grading and Drainage – Overall Key Plan
9 06-Y-1000 Overall Yard Piping Plan
10 09-E-1000 Electrical Site Plan – Overall
11 10-A-0050 Renderings
12 10-E-6000 Electrical – Single Line Diagram
13 98-X-6001 Electrical Main Single Line Diagram Demolition
14 98-X-6010 Electrical Emergency Power Single Line Diagram
15 98-E-6001 Electrical Main Single Line Diagram Revised
16 98-E-6011 Electrical Overall Single Line Diagram 44-MSG-01
Resolution No. 10930 (2018 Series)
EXHIBIT A Page 83
FILENAME:PLOT DATE:PLOT TIME:10/19/20171:52:00 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017M
ENTOSOLANOPLACERSA
CRA-SONOMALAKENAPAYOLOALPINEMONOINYOMARIPOSATUOLUMNEAMADOREL DORADOSTA
NISLA
US CALAVERAS DEL NORTEMODOCSUTTERSISKIYOUTRINITYHUMBOLDTLASSENSHASTAYUBA GLENNBUTTEMENDOCINOCOLUSASIERRANEVADATEHAMAPLUMASLUISSAN BARBARAOBISPOTULAREMONTEREYKERNKINGSSANTARIVERSIDESAN BERNARDINOSAN DIEGOIMPERIALVENTURALOSANGELESORANGEALAMEDASANTAS
A
N
JO
A
Q
UIN
MERCEDM
A
DER
ACLARACRUZ CONTRAFRESNOSANTASANBENITOMARINCOSTASAN MATEOSAN FRANCISCOExp.L STED
NEIESTATE OF CLF
ORNI
A06-30-2018REG
IER P
ROFSSEOIAL NGNER ICVI
AI No. C37237NAIHSUOSORONOD
A
RIEF
01-G-0001 G ENERAL
A HOW EB ROUSH01-G-0001_668876.dgnRECOVERY FACILITY PROJECTWATER RESOURCECITY OF SAN LUIS OBISPO, CALOS OSOS VALLEY ROADU.S. HI
GHW
AY 101SOUTH HIGUERAMADON
N
A RO
A
D
TANK FARMHIGUERALOCATION PLANNTSVICINITY MAPNTSNNVICINITYPROJECTLOCATIONPROJECTTL BAUER
TITLE, VICINITY AND
LO CATION M APS OCTOBER 201760% SUBMITTAL DRAWINGSResoution No. 10930
EXHIBIT A Page 84
MMSSFILENAME:PLOT DATE:PLOT TIME:10/19/20171:52:01 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017Exp.L STED
NEIESTATE OF CLF
ORNI
A06-30-2018REG
IER P
ROFSSEOIAL NGNER ICVIAI No. C37237NAIHSUOSORONOD
A
RIEFSTRUCTUREPOND CONTROLEQUALIZATIONPONDEQUALIZATIONFLOWTREATMENTSIDESTREAMDAFT TANK)TANK (EXISTINGBLENDINGSLUDGECLARIFIER 1PRIMARYCLARIFIER 2PRIMARYCOMPACTORWASHER/SCREENINGSBINSCREENINGSBINGRITSCREENINGS HANDLINGGRIT HANDLINGGRIT PUMPSWWWWHEADWORKSINFLUENT PSRAKECHAINRAKECHAINPIPIPEPEPSPSCPSCPSPRESSSCREWPRESSSCREWCOMPOSTINGFILL / OFFSITETO LANDSLUDGE PUMPSTHICKENEDMSBSPSPS
PUMPSSLUDGEPRIMARYBSBOXJUNCTIONINFLUENTLIQUIDS AND SOLIDS PROCESS FLOW DIAGRAMPSCSEE 01-G-0042FOR CONTINUATION,
01-G-0041KL M CCOY01-G-0041_668876.dgn G ENERAL
PRO CESS FLO W DIAG RAM
TR GREELEYFC PEDSDSTFTFLIQUIDS AND SO LIDS 1(2)PUMPSFILTRATE(2)FEED PUMPSSIDESTREAMSEE 01-G-0042FOR CONTINUATION,PE SCREENS,PS (BYPASS) TO THICKENER 1SCREWTHICKENER 2SCREWBLOWERS (2)AGITATION AIRFCRACKBAR(2)SEPARATORGRITSLEGENDEQUALIZATIONFILTRATEDEWATERINGTANKSTORAGESLUDGEFILTSEE DWG 01-G-0042TO PE SCREENS,POS
POSPOSWW / RW W / R
PE / BYPJUNCTION BOXNITRIFIED EFFLUENTDIVERSION TOEMERGENCYPUMPS (2)FILTRATEBSBSWASBSTANK 1FLOCTANK 2FLOCTHSTHSDIGESTER 1DIGESTER 2FCFCPOSPOSPE / RPE / OFPI / OFREMOVAL TANKSAERATED GRITSTATIONSDRAIN PUMPUNIT 3 & 4 PLANTFILTTANK 1FLOCTANK 2FLOCDSDSFILTFILTPUMPSRETURNEQ PONDPDPDMMMMM
MMMMBSMBSMFEED PUMPSDEWATERINGDSPUMPSFEEDTHICKENERMSBOXDIVERSION EFFLUENTPRIMARY FILT
MFLOW MEASUREMENTGATE, NORMALLY CLOSEDGATE, NORMALLY OPENWET WEATHER EQUALIZATION FLOWAUTOMATIC SAMPLER LOCATIONWWWWWWWWPUMPSSCUMPRIMARYPSC/ DECANTWETWELLPO S
MMResoution No. 10930
EXHIBIT A Page 85
FILENAME:PLOT DATE:PLOT TIME:10/19/20171:51:40 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017Exp.L STED
NEIESTATE OF CLF
ORNI
A06-30-2018REG
IER P
ROFSSEOIAL NGNER ICVIAI No. C37237NAIHSUOSORONOD
A
RIEFLIQUIDS PROCESS FLOW DIAGRAMBINSCREENINGSSEE 01-G-0041SLUDGE PUMPS,FROM PRIMARYPE SCREENSPEPEBIRASBIOREACTOR 1BIOREACTOR 2BIOREACTOR 3BIOREACTOR 4RASPUMPSPERMEATEWASPER1TANK2TANK3TANK4TANK5TANKDWG 01-G-0041CONTINUATIONBLENDING. FORWAS TO SLUDGEPS - BYPASS
KL M CCOY01-G-0042_668876.dgnG ENERAL
PRO CESS FLO W DIAG RAM
TR GREELEY01-G-0042 LIQUIDS AND SO LIDS 2 SREUSEFUTURETOPUMPSWASPUMPSFEEDMEMBRANERASSEE DWG 01-G-0041CLARIFIERS,FROM PRIMARY(2)COMPACTORSWASHERRASPOND 1PLANT EFFLUENTPOND 2PLANT EFFLUENTDIVERSION BOX 2PLANT EFFLUENTOUTFALL STRUCTUREPLANT EFFLUENTEFFRWROBISPO CREEKSAN LUISDISTRIBUTIONWATERTO RECYCLEDDIVERSION BOX 1PLANT EFFLUENTALP
EFFEFFTANKWATERRECYCLEDUVUVUVASBLOWERS (6)AIR SCOURBLOWERSAERATIONTOWERSCOOLINGPUMPSTOWERCOOLINGM3WUSESTO PLANT3W PUMPSSJUNCTION BOXPLANT EFFLUENTNAOHMMMMUVMUVMUVMUVMUVMUVMMM6TANKMMMMMMMMMMCAOH
C
CAOH/D
RWRUV SYSTEM(8)PUMPSMLRSHSHResoution No. 10930
EXHIBIT A Page 86
FILENAME:PLOT DATE:PLOT TIME:10/23/201712:08:47 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017 Exp.L STED
NEIESTATE OF CLF
ORNI
A06-30-2018REG
IER P
ROFSSEOIAL NGNER ICVIAI No. C37237NAIHSUOSORONOD
A
RIEF
KL M CCOY01-G-0043_668876.dgnG ENERAL
TR GREELEY01-G-0043 NOTES:1.2. 3.LEGENDPEAK HOURMAXIMUM EQUALIZED FLOWPRIMARY CLARIFIERS TO EQUALIZATION POND.FLOW IN EXCESS OF 22 MGD BYPASSES EQUALIZATION POND.PRIMARY EFFLUENT DIVERSION BOX TO FLOW IN EXCESS OF 16 MGD OVERFLOWS AT HEADWORKS TO EQUALIZATION POND.FLOW IN EXCESS OF 33 MGD BYPASSES MAXIMUM MONTHAVERAGE ANNUAL FLOW4.EXISTING STRUCTURES.FLOOD PROTECTION PROVIDED AROUND5.AT PEAK HOUR.SHADING ILLUSTRATES WATER SURFACEMINIMUM FLOW100 YR FLOOD133.80110115120125130135FO R CONTINUATION, SEE ABOVE
SCREENSFINE1 THRU 4BIOREACTORSBASINSMEMBRANEEL 114.62EL 137.00EL 125.00105ANOXICAEROBIC130.52130.48130.69130.70130.02129.98130.19130.20130.00129.96130.10130.11129.79127.71129.72129.79128.18128.11129.38129.48129.17129.10129.32125.21125.11125.59125.59135.00135.00135.00135.00NOTE 4EL 135.0030" RAS (4)129.85129.84129.01128.87128.87125.01135.00110115120125130135105FO R CONTINUATION, SEE 01-G-0043AFEED PUMPSMEMBRANE14014036" PE125.00125.00125.00125.00125.00EL 135.00EL 125.00129.40130.35115120125130135140FOR CONTINUATION, SEE BELO WSCREENSINFLUENTSTATIONINFLUENT PUMPFLUMEPARSHALLCLARIFIERSPRIMARY115120125130135140100 YR FLOOD100 YR FLOOD135.60134.10IE 125.65EL 119.70132.34WEIR EL48" WW131.95EL 114.9554" INFEL 126.15EL 134.45128.60128.55129.55129.57128.51128.51128.55128.71EL 124.20GRIT TANKSAERATED110110BOXDIVERSIONEFFLUENTPRIMARY128.00128.00128.00128.00EL 130.65, NOTE 3OVERFLOW WEIRSTRUCTUREPOND CONTROLEQUALIZATION136.99137.08135.30135.13136.63136.40135.27135.12136.01136.01135.00134.79134.89134.90134.12134.0336" PE36" PE132.49132.49132.44132.43132.32131.92131.45131.41131.46131.24130.73130.73EL 136.50TOWNOTE 4EL 132.95EL 135.99, NOTE 1OVERFLOW WEIR30" PI (2)NOTE 2EL VARIES,EL 138.45TOW130.35131.35133.69132.38128.51128.50128.00134.87134.79134.87EL 133.84PONDEQUALIZATIONTO FLOW48" INFEL 130.34EL 131.34TO EQUALIZATION POND36" PIEL 134.82WEIREL 133.85EL 133.85EL 133.60EL 124.45MM36" PE/OFEQUALIZATION PONDEL 138.90EL 124.00 - 126.00140135130125120115DIVERSION BOXFROM PRIMARY EFFLUENT FROM HEADWORKSSTRUCTUREPOND CONTROLFROM EQUALIZATION MAX HGL134.75SEE 01-G-0043ATO UV TREATMENT EL 126.12EL 129.80WEIR EL 122.25EL 126.63EL 126.63EL 128.80WEIR EL 120.0048" MLEL 135.00XXXXXXXXXXXXXXXHYDRAULIC PRO FILE 15.ELEVATION UNITS ARE IN FEET.Resoution No. 10930
EXHIBIT A Page 87
FILENAME:PLOT DATE:PLOT TIME:10/23/201712:08:40 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017 0.00
Exp.L STED
NEIESTATE OF CLF
ORNI
A06-30-2018REG
IER P
ROFSSEOIAL NGNER ICVIAI No. C37237NAIHSUOSORONOD
A
RIEF
01-G-0043A_668876.dgnG ENERAL
LEGENDPEAK HOURMAXIMUM EQUALIZED FLOWMAXIMUM MONTHAVERAGE ANNUAL FLOW
KL M CCOYTR G REELEY80859095100105110115120 125130135DISINFECTIONUVOUTFALL STRUCTUREPLANT EFFLUENT100 YR FLOOD100 YR FLOOD110.05EL 112.95EL 97.95CREEKOBISPOSAN LUIS24" EFFIE 89.95IE 91.45DIVERSION BOX 2PLANT EFFLUENT36" EFFIE 85.45119.39119.28119.09118.98112.78111.36EL 115.95EL 106.45EL 82.45110.81110.5691.56140121.94122.57122.41119.10119.63119.49126.60118.61110.5491.45121.38118.62122.11119.2491.66EL 106.45EL 111.95TOWERCOOLING 111.43111.23110.99110.89110.53EL 121.25WEIREL 128.95MINIMUM FLOW8085909510010511011512012513013514024" EFFEL 105.29FOR CONTINUATION, SEE 01-G-0043
BASINSMEMBRANE FROM EL 111.70WEIR EL 110.4536" EFF01-G-0043A112.13EL 95.00DIVERSION BOX 1PLANT EFFLUENT111.08EL 120.50TOWTIE IN BOXOUTFALL EL 117.0036" EFFMMTO REUSEEL 129.70MAX HGL 122.00TANKRECYCLED WATERCL 126.6130" EFFEL 111.70122.00TO EXCEED THIS BOX NOT ELEVATION IN 30" EFFWATER TANKTO RECYCLED EL 122.00OVERFLOWREUSE BASIN EL 118.50TOW EL 129.7WEIR EL 124.624" EFF30" PER42" EFFXXXXXXXXXXXXXXXHYDRAULIC PRO FILE 2 DISINFECTIONFROM UVNOTES:1.2.3.PRIMARY CLARIFIERS TO EQUALIZATION POND.FLOW IN EXCESS OF 22 MGD BYPASSES EQUALIZATION POND.PRIMARY EFFLUENT DIVERSION BOX TO FLOW IN EXCESS OF 16 MGD OVERFLOWS AT HEADWORKS TO EQUALIZATION POND.FLOW IN EXCESS OF 33 MGD BYPASSES 4.EXISTING STRUCTURES.FLOOD PROTECTION PROVIDED AROUND5.AT PEAK HOUR.SHADING ILLUSTRATES WATER SURFACE5.ELEVATION UNITS ARE IN FEET.Resoution No. 10930
EXHIBIT A Page 88
30" INF WWCONNECTED TO48" INF WW30" INF WW
48" INF WW30" WW/PE (BYPASS)48" INF WW30" INF WW128.54SSMH129.70SSMH131.91SSMH137.49104107137.86134.89134.28135.03110105109113W.L.125.34-14-144-14-14127.6W.L.4-14-14126.7W.L.4-14-14129.7W.L.129.41124.28130.281061024-14-14W.L.4-14-14W.L.4-14-14W.L.4-14-14W.L.COCOSCOCOSSCOCOSCOSCOSSCOCOSSCOSCOSCOSCOSCOCOSSSSCOCOCOCOSCOSCOCOCOSCOSSSCOCOSSCOCOCOCOCOCOCOCOSCOCOSCOCOSSCOCOSCOCOCOCOCOCOCOSCOSCOCOCOCOCOCOCOSSCOCOSSCOSCOCOCOSCOCOCOCOCOCOCOCOCOSCOCOCOSSSCOSCOCOCOSSCOSSSCOSSSSCOSSCOCOSCOCOCOCOCOCOCOSSSCOCOSSCOSCOVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVVLVSSVLVVLVVLVCOSSVLVVLVWWCOCOSSSSCOSCSSCO130.6130.7131.0131.0AREA 1AREA 2AREA 9AREA 11AREA 6AREA 10AREA 12AREA 3FILENAME:PLOT DATE:PLOT TIME:10/18/201711:28:29 AMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.ANSI_D_668876.dgn668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017Exp.L STED
NEIESTATE OF CLF
ORNI
ANo. C 6657306-30-2018REG
IER P
ROFSSEOIAL NGNERHTOBON ANELLNJAE
ICVI
AI080160240Scale In FeetNFACILITY LEGEND12141520304244465052556070808486252643SAN LUIS OBISPO CREEKAREA 4AREA 5AREA 8AREA 7SEE FACILITY 14 DEMOLITION DRAWINGS FOR DEMOLITION IN THIS AREA.4.DEMOLITION.SEE 05-XC-5003 FOR DETAIL OF SECONDARY CLARIFIER MECHANISM 3.SEE 05-XC-5002 FOR DETAIL OF COOLING TOWER DEMOLITION.2.FACILITY.SEE 05-XC-5001 FOR DETAIL OF DEMOLITION OF AQUEOUS AMMONIA 1.GENERAL NOTES:NOTE 4LAGOONSUPERNATANT CONTROL HOUSEPUMP STATIONRECIRCULATION NOTE 3(MECHANISM ONLY),SECONDARY CLARIFIERRESEARCH CENTERCAL POLY BIOFILTER 3DRYING BEDSSLUDGE AND 9BPONDS 9A JONES TRAILBOB BLOWER STRUCTURESTATIONCHLORINATION(MECHANISM ONLY)FINAL CLARIFIERSSTORAGE SHEDFACILITY, NOTE 1AQUEOUS AMMONIA SLUDGE DRYING BEDSBONE YARD
05-XF-1000_668876.dgn05-XF-1000
A HOW E
CIVIL
D PETERSONAIR GAP STRUCTURESTORAGEPROPANE EXST 2" 1WEXST 3" 3WCONNECTIONCAP EXST FDC DEMOLISH AND 86142526911520208480709442424430431246529750505560SECONDARY CLARIFIER FINAL CLARIFIERSBIOREACTOR BASINS 1 AND 2RECIRCULATION PUMP STATIONBOX 1 (PED B1)PRIMARY EFFLUENT DIVERSIONPRIMARY CLARIFIERSHEADWORKSEQUALIZATION PONDPROCESS LABMCC-J BUILDINGMCC-G BUILDINGMCC-B BUILDINGMCC-A BUILDINGODOR CONTROLDEWATERINGCOGENERATIONDIGESTER NO. 1SOLIDS BLEND TANKRECYCLED WATER TANKCHLORINE CONTACT BASINS / 3W PUMPSCOOLING TOWERSEQUALIZATION BASINSFILTERSSWITCHGEAR BUILDING889097949188(MECHANISM ONLY)PRIMARY CLARIFIERSOVERALL SITE FACILITY AND PIPING
DEM O LITION PLAN DIVERSION BOXSECONDARY EFFLUENT PUMP STATIONPRIMARY SLUDGE 1 AND 2BIOFILERS 90DIVERSION BOXPRIMARY EFFLUENT XF-1007XY-1008XF-1004XF-1008BICYCLE SHEDNOTE 2TOWERS,COOLING XY-1004XY-1005Resoution No. 10930
EXHIBIT A Page 89
FILENAME:PLOT DATE:PLOT TIME:CH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUMENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUMENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUMENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG Aof$PWPATHCH2M HILL AND IS NOT TO BE USED, IN WHOLE OR IN PART, FOR ANY OTHER PROJECT WITHOUT THE WRITTEN AUTHORIZATION OF CH2M HILL.$PWURL66887660% DESIGN
WATER RESOURCE RECOVERYOCTOBER 2017APPVD BY--------FACILITY PROJECT
CIVIL
SITE PLAN
OVERALL KEY PLAN
J TOMAC J TOMAC K KAUO05-C-1000CIVIL05-C-1000_668876.dwgFACILITY KEYWATER RESOURCE CENTERAIR GAP BUILDINGPROCESS LAB (EXISTING)EQUALIZATION PONDHEADWORKS (EXISTING)FERRIC CHLORIDE FACILITY (EXISTING)PRIMARY INFLUENT FLOW METER VAULTPRIMARY CLARIFIERS (EXISTING)PRIMARY EFFLUENT FLOW METER VAULTPRIMARY SLUDGE PUMP STATIONPRIMARY EFFLUENT DIVERSIONBOX 1 (EXISTING)RECIRCULATION PUMP STATION (EXISTING)PRIMARY EFFLUENT DIVERSIONBOX 2 (EXISTING)PRIMARY EFFLUENT SCREENINGCALCIUM HYDROXIDE FACILITYBIOREACTOR BASINS 1 & 2 (EXISTING)AERATION BLOWERSBIOREACTOR BASINS 3 & 4CHEMICAL STORAGE FACILITYMEMBRANE BUILDINGFINAL CLARIFIERS (EXISTING)SECONDARY CLARIFIER (EXISTING)SWITCHGEAR BUILDING (EXISTING)FILTERS (EXISTING)EQUALIZATION BASINS (EXISTING)CHEMICAL STORAGE BUILDING (EXISTING)COOLING TOWERS (EXISTING)UV ELECTRICAL BUILDINGUV DISINFECTIONCHLORINE CONTACT BASIN/3W PUMPS (EXISTING)RECYCLED WATER FLOW METER VAULTRECYCLED WATER TANK (EXISTING)SIDESTREAM TREATMENTEFFLUENT COOLINGSOLIDS BLEND TANK (EXISTING)THICKENINGSOLIDS ELECTRICAL BUILDINGDIGESTER NO. 1 (EXISTING)DIGESTER NO. 2DIGESTER BUILDINGCOGENERATION (EXISTING)DIGESTED SLUDGE STORAGE TANKDEWATERING (EXISTING)ODOR CONTROL (EXISTING)MCC-A BUILDINGMCC-B BUILDINGMCC-G BUILDINGMCC-R BUILDINGMCC-J BUILDING1012141520223035364042434446505254556064707280828384868810121415202022303640424243444650505255607072808283848688542526272927HWY 101SLO CREEKPRADO ROADSLO CREEK0100 200 3001" = 100'7373GENERAL NOTES1. THE HORIZONTAL CONTROL FOR THIS PROJECT IS NAD 83 ZONE 5STATE PLANE COORDINATES AS PUBLISHED IN THE CITY OF SANLUIS OBISPO'S HORIZONTAL CONTROL NETWORK.THE BENCHMARK USED FOR THIS MAPPING WAS THE CITY OF SANLUIS OBISPO'S BM NO. 53 HAVING A PUBLISHED NAVD88 ELEVATIONOF 134.44 AND IS DESCRIBED AS A L&T AT THE BCR AT THE NEC OFPRADO ROAD AND ELKS LANE.2628NO. 75284EXP.35851010AREA 12AREA 10AREA 7AREA 11AREA 8AREA 9AREA 5AREA 6 - NOT USEDAREA 2AREA 1AREA 4AREA 3BOB JONESTRAIL6868CONTRACTORSTAGING AREA53531164111618212934515885909194965851979490182591GENERATOR34BENCHMARK NO. 539616971128Resoution No. 10930
EXHIBIT A Page 90
FILENAME:PLOT DATE:PLOT TIME:CH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUMENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUMENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUMENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG Aof$PWPATHCH2M HILL AND IS NOT TO BE USED, IN WHOLE OR IN PART, FOR ANY OTHER PROJECT WITHOUT THE WRITTEN AUTHORIZATION OF CH2M HILL.$PWURL66887660% DESIGN
WATER RESOURCE RECOVERYOCTOBER 2017APPVD BY--------FACILITY PROJECT
CIVIL
GRADING & DRAINAGE
OVERALL KEY PLAN
J TOMAC J TOMAC K KAUO05-CG-100005-CG-1000_668876.dwg080160 2401" = 80'SLO CREEKSLO CREEKPRADO ROAD HWY 101GENERAL NOTES1. THE HORIZONTAL CONTROL FOR THIS PROJECT IS NAD 83 ZONE 5STATE PLANE COORDINATES AS PUBLISHED IN THE CITY OF SANLUIS OBISPO'S HORIZONTAL CONTROL NETWORK.THE BENCHMARK USED FOR THIS MAPPING WAS THE CITY OF SANLUIS OBISPO'S BM NO. 53 HAVING A PUBLISHED NAVD88 ELEVATIONOF 134.44 AND IS DESCRIBED AS A L&T AT THE BCR AT THE NEC OFPRADO ROAD AND ELKS LANE.BENCH MARKNO. 53NO. 75284EXP.AREA 12AREA 10AREA 7AREA 11AREA 8AREA 9AREA 5AREA 6 - NOT USEDAREA 2AREA 1AREA 4AREA 3Resoution No. 10930
EXHIBIT A Page 91
FILENAME:PLOT DATE:PLOT TIME:10/19/201711:28:50 AMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.ANSI_D_668876.dgn668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017Exp.L STED
NEIESTATE OF CLF
ORNI
ANo. C 6657306-30-2018REG
IER P
ROFSSEOIAL NGNERHTOBON ANELLNJAE
ICVI
AI080160240Scale In FeetN2.1.NOTES:FACILITY LEGEND101214152022303536404244465052545560647072808283848688252627
A HOW E06-Y-1000YARD PIPING7343
J KOCH2815 20202235304043448570728284868336804242SAN LUIS OBISPO CREEK8825272873GENERATOR64261014AREA 1AREA 2AREA 4AREA 5AREA 8AREA 9AREA 11AREA 65412465052BE REPLACEDSD SYSTEM TO RECEIVINGFUTURE FOG AREA 7AREA 10AREA 12506055AREA 36868STATIONFILTRATE PUMP DEWATERING PUMP STATIONWATER REUSE GENERATORLAGOONSUPERNATANT EXST STRUCTURECONTROL EXST EQ POND 1116182129535158859091949697EXISTING PIPING FOR CLARITY.NEW ELECTRICAL IS SCREENED WITH CONSTRUCTION.AREAS OF EXISTING UTILITIES DURING DELIVERIES AND PLANT PERSONNEL TO ALL CONTRACTOR TO MAINTAIN ACCESS FOR 965853519794TRANSFER PUMP STATIONDIGESTED SLUDGE 18901621912911DIVERSION BOXEFFLUENT NITRIFIED 10FILTERS (EXST)SWITCHGEAR BUILDING (EXST)SECONDARY CLARIFIER (EXST)FINAL CLARIFIERS (EXST)MEMBRANE BUILDINGCHEMICAL STORAGE FACILITYBIOREACTOR BASINS 3 AND 4(EXST)BIOREACTOR BASINS 1 AND 2 CALCIUM HYDROXIDE FACILITYPRIMARY EFFLUENT SCREENINGBOX 2 (PED B2)PRIMARY EFFLUENT DIVERSION(EXST)RECIRCULATION PUMP STATION BOX 1 (PED B1) (EXST)PRIMARY EFFLUENT DIVERSIONPRIMARY SLUDGE PUMP STATIONPRIMARY EFFLUENT FLOW METERPRIMARY CLARIFIERS (EXST)PRIMARY INFLUENT FLOW METERFERRIC CHLORIDE BUILDING (EXST)HEADWORKS (EXST)EQUALIZATION PONDPROCESS LAB (EXST)AIR GAP BUILDINGWATER RESOURCE CENTERMCC-J BUILDINGMCC-R BUILDINGMCC-G BUILDINGMCC-B BUILDINGMCC-A BUILDINGODOR CONTROLDEWATERING (EXST)DIGESTED SLUDGE STORAGE TANK (EXST)COGENERATION (EXST)DIGESTER BUILDINGDIGESTER NO. 2DIGESTER NO. 1 (EXST)SOLIDS ELECTRICAL BUILDINGTHICKENINGSOLIDS BLEND TANK (EXST)EFFLUENT COOLINGSIDESTREAM TREATMENTRECYCLED WATER TANK (EXST)RECYCLED WATER FLOW METERCHLORINE CONTACT BASINS / 3W PUMPS (EXST)UV DISINFECTIONUV ELECTRICAL BUILDINGCOOLING TOWERSCHEMICAL STORAGE BUILDINGEQUALIZATION BASINS (EXST)
OVERALL YARD PIPING PLAN
Resoution No. 10930
EXHIBIT A Page 92
FILENAME:PLOT DATE:PLOT TIME:10/17/20178:18:22 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.ANSI_D_668876.dgn668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017EGIS
T
ERED
P
ROFESSIONALENGINEERSTATEOFCALI
F
OR
NI
AELECTRI
C
R
AL No. E18650Exp.12-31-18B
AMEHWYSAE
T080160240Scale In FeetNFACILITY LEGEND1012141520223035364042444650525455607072808283842527
09-E-100073432820304043443642251412465052TRANSFER PUMP STATIONDIGESTED SLUDGE 506055A M ATHEW S
SITE ELECTRICALSITE PLAN - OVERALL1.:NOTESPUMP STATIONWATER REUSE DIVERSION BOXNITRIFIED EFF SAN LUIS OBISPO CREEKNOTE 154352810AREA 12AREA 10AREA 3AREA 7AREA 11AREA 1AREA 4AREA 8AREA 9AREA 5AREA 2AREA 6SITE PLAN - OVERALL
ELECTRICAL6468 6822SL GOODRICH JK LANDM AN GENERATOR6453537372708280208385881584861010421116182129115158TO REROUTE ALL CIRCUITS AS NECESSARY.A NEW DUCTBANK WILL BE CONSTRUCTED EXISTING DUCTBANK WILL BE DEMOLISHED. 8688909194968558519794272129111690LOCATIONUTILITY POLECOMM MHCOMM MHCOMM MHMCC-J BUILDINGMCC-R BUILDINGMCC-G BUILDINGMCC-B BUILDINGMCC-A BUILDINGODOR CONTROLDEWATERING BUILDINGDIGESTED SLUDGE STORAGE TANK979691BUILDINGDEWATERING FINAL CLARIFIERSMEMBRANE BUILDINGCHEMICAL STORAGE FACILITYBIOREACTOR BASINS 3 & 4BIOREACTOR BASINS 1 & 2CALCIUM HYDROXIDE FACILITYPRIMARY EFFLUENT SCREENSBOXPRIMARY EFFLUENT DIVERSIONBOX (EXISTING)PRIMARY EFFLUENT DIVERSIONPRIMARY SLUDGE PUMP STATIONVAULTPRIMARY EFFLUENT FLOW METER PRIMARY CLARIFIERSVAULTPRIMARY INFLUENT FLOW METER FERRIC CHLORIDE FACILITYHEADWORKSEQUALIZATION PONDPROCESS LABAIR GAP BUILDINGWATER RESOURCE CENTERCOGENERATIONDIGESTER FACILITYDIGESTER NO. 2DIGESTER NO. 1SOLIDS ELECTRICAL BUILDINGTHICKENINGSLUDGE BLEND TANKEFFLUENT COOLINGSIDESTREAM TREATMENTRECYCLED WATER TANKRECYCLED WATER FLOW METER VAULTCHLORINE CONTACT BASINSUV DISINFECTION UV ELECTRICAL BUILDINGCOOLING TOWERSCHEMICAL STORAGE (EXISTING)EQUALIZATION BASINSFILTERSSWITCHGEAR BUILDINGSECONDARY CLARIFIER GEARPG&E METERINGResoution No. 10930
EXHIBIT A Page 93
VERIFY SCALEAPVDBYREVISIONCHKDRDATEDSGNNO.APVDDATEPROJDWGSHEET60% DESIGNTHIS DOCUMENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUMENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUMENTS:BAR IS ONE INCH ONORIGINAL DRAWING.CH2M HILL AND IS NOT TO BE USED, IN WHOLE OR IN PART, FOR ANY OTHER PROJECT WITHOUT THE WRITTEN AUTHORIZATION OF CH2M HILL.6688761"0CH2M HILL 2017. ALL RIGHTS RESERVED.cBCDA123456JEFFERY J. MCGRAWC-24100"NOT FOR CONSTRUCTION"WATER RESOURCE RECOVERYFACILITY PROJECT10/17/2017 10:10:27 AMC:\Users\lrandolph\Documents\WRC Central_60%_lrandolph.rvtSEPTEMBER 2017WATER RESOURCE CENTERRENDERINGSJ. MCGRAWJ. MCGRAWL. RANDOLPHJ. ROOT10-A-0050ARCHITECTURAL-1PERSPECTIVE LOOKING SOUTHEAST-2PERSPECTIVE LOOKING NORTHWESTResoution No. 10930 EXHIBIT APage 94
600AT600AF'10-SWBD-LV' 600A,120/208V, 3PH, 4W, 65kAIC, NEMA 1225A3PUNDERGROUNDPULLSECTIONNG#___MECHPANEL225A3P225A3P225A3P225A3P225A3P300A3P225A3P225A3P225A3P10-ACCU-01(17.6 MCA)25A3P15A3P600A3P800AT1200AFUNDERGROUNDPULLSECTIONG10-AHU-023A3P10-AHU-015A3P10-XFMR-01225 KVA480-120/208300A3PUNDERGROUNDPULL SECTION10-XFMR-PV500 KVA480-480/277(IF REQUIRED BYPV INSTALLER)SPACE10-ACCU-02(8.4 MCA)7.0KVA14.6KVA20A3P10-ACCU-03(13.0 MCA)10.8KVA__A3P10-ACCU-04(__ MCA)__KVA7A3P10-DOAS-01(5.0 MCA)4.2KVA15A3P10-EWH-01(10.8 FLA)9.0KW15A3P10-EWH-02(10.8 FLA)9.0KW15A3P20A3PSPARESPARESPACEMECHPANELMECHPANELMECHPANELPOWERPANELLIGHTINGPANELPOWERPANELLIGHTINGPANELPOWERPANELLIGHTINGPANELPOWERPANELLIGHTINGPANELPOWERPANELLIGHTINGPANELPOWERPANEL(F)POWERPANEL(F)MECHPANEL1. SEE GENERAL NOTES AND SYMBOLS ON SHEET10-E-0900.MEQUIPMENT DESIGNEDAND INSTALLED BY PVSYSTEM INSTALLER600A3P'10-PNL-PV', 600A480V, 3PH, 4W, 65 KAIC NEMA 140A3P20A3P20A3P40A3P125A3P250A3P10-PV-0110-PV-CANOPY-0110-PV-CANOPY-02EQUIPMENT DESIGNED ANDINSTALLED BY PV SYSTEMINSTALLER10-PV-0210-PV-0310-PV-04SINGLE LINE DIAGRAM - METEREDSCALE: 1/4"=1'-0"GENERAL NOTESKEYED NOTES1MAIN BREAKER SHALL BE BACK-FED CAPABLE.2 BREAKER MUST BE LOCATED AT FURTHESTBREAKER LOCATION. DO NOT RELOCATEDBREAKER. LABEL PER NEC 705.12(D)(2)(3).3 COORDINATE NUMBER OF BREAKERS AND SIZESWITH PV SYSTEM INSTALLER.'10-SWBD' 1200A480V, 3PH, 3W, 65kAIC, NEMA 110-PNLM1A10-PNLM1B10-PNLM2A10-PNLM2B10-PNLP1A10-PNLL1A10-PNLP1B10-PNLL1B10-PNLP1C10-PNLL1C10-PNLP1D10-PNLL1D10-PNLP2A10-PNLL2A10-PNLP2B10-PNLP1E10-PNLM1C3121FILENAME:PLOT DATE:PLOT TIME:CH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUMENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUMENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUMENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN WHOLE OR IN PART, FOR ANY OTHER PROJECT WITHOUT THE WRITTEN AUTHORIZATION OF CH2M HILL.PRELIMINARYNOT FOR CONSTRUCTION66887660% DESIGNSEPTEMBER 2017APPVD BY10/23/20179:51 AMWATER RESOURCE RECOVERY
FACILITY PROJECT
G OTTO BM APFEL NO. 16396D
E
REK E. ROMERR EGISTE
R
E
D PROFESSIONAL ENGINEERSTATE OF CALI
FORN
IA EXP. 06-30-19ELECTRICAL
WATER RESOURCE CENTER
ELECTRICAL DRAWINGS
SINGLE LINE DIAGRAM10-E-6000#10-E-6000.DWGResoution No. 10930
EXHIBIT A Page 95
FILENAME:PLOT DATE:PLOT TIME:10/17/20174:24:50 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017EG IS
T
ERED
P
ROFESSIONALENGINEERSTATEOFCALI
FOR
NI
AELECTRI
C
R
AL No. E18650Exp.12-31-18B
AMEHWYSAE
T
98-X-6001XXELECTRICAL
PLANTW IDE ELECTRICAL
M AIN SING LE LINE DIAG RAM
DEM O LITION
SL GOODRICH98-X-6001_668876.dgn3286KMH3AUXILIARY LOADS)(INDUCTION GENERATORENGINE BUILDINGSLUDGE GASMCC-D3EME 151EME 152PONDEQUALIZATIONMCC-C3EME 2513EME 25233EME 851EME 85233TREATMENT)(SECONDARYAIRAERATIONMCC-F1STRUCTUREDAFMCC-G1STRUCTUREDAFMCC-G2TREATMENT)(SECONDARYAIRAERATIONMCC-F23EME 805BUILDINGSWITCHGEARMCC-HA
AS3GND BUS74FOR KW RECORDERTERMINAL STRIP480-120V480-120V480-120V2248V DC BUSSWITCHGEARGENERATORINDUCTION EXISTINGEMZ 004TO TO DPCMSCREENINGSINFLUENT/MCC-A1SCREENINGSINFLUENT/MCC-A2BIOFILTERSCLARIFIERSMCC-B1BIOFILTERSCLARIFIERSMCC-B2AREAUNIT 4MCC J1AREAUNIT 4MCC J2MCC-J1EMCC-J2EEG/CB-5FROM SWBDEG/CB-4FROM SWBDEG/CB-7FROM SWBDEG/CB-4FROM SWBDEG/CB-3FROM SWBDEG/CB-1FROM SWBDEG/CB-2FROM SWBDLO SS OF DC
BUILDINGLOCATED IN SWITCHGEARMAIN SWITCHGEAR "MSG"P.G. & E. METERING SECTIONP.G. & E. SECTIONSMCC B BUILDINGLOCATED INMCC A BUILDINGLOCATED INSWITCHDISCONNECT200A, 3P, 600VDS EMZ 004BUS EXTENSIONPROVISIONS FOR FUTURE480V, 3PH, 4W, 3000A COOPER BUS480V, 3PH, 4W, 3000A COOPER BUSAASAASAASAASAASAASAASAASAASVVSALARM
CONTROL PW R TO DPC3000:53000:53000:53000AF3000AT52-M800 AT800 AF52-10400 AT800 AF52-91200 AT1600 AF52-81200 AT1600 AF52-7800 AT800 AF52-6400 AT800 AF52-1400 AT800 AF52-2300 AT800 AF52-3300 AT800 AF52-4800 AT800 AF52-5SECTIONINCOMING MCC J BUILDINGLOCATED INBUILDINGSWITCHGEAR LOCATED IN12KV DISTRIBUTION LINENOTE 2NOTE 3JK LANDM ANA M ATHEW S "MSG-T"PAD MOUNTED TRANSFORMERNOTE 3NEW SWITCHGEAR 44-MSG-01.EXISTING TRANSFORMER "MSG-T" WILL BE REFED FROM 4.EXISTING PG&E TO BE REMOVED BY PG&E.NEW PG&E METER IS INSTALLED AND OPERATIONAL. EXISTING PG&E METERING TO REMAIN IN PLACE UNTIL 3.ENSURE SERVICE INTERRUPTIONS ARE MINIMIZED.OWNED BY THE CITY. PHASE WORK WITH NEW WORK TO PROJECT EXISTING TRANSFORMER. TRANSFORMER IS 2.AND LOAD FEEDER CONDUIT FOR REUSE.FEEDER. PROTECT "NORMAL" SOURCE FEEDER CONDUIT AND ALL EXPOSED CONDUIT FOR THE "STANDBY" SOURCE DEMOLISH ATS, ALL SOURCE AND LOAD CONDUCTORS, 1.NOTES:ALL ATSsTYP OFNOTE 1, NEMA 1480V, 400A, 65 KAICENCLOSED BREAKERNEMA 3R480V-480Y/277V260KVANEMA 3R600V, 400A, 3-PHASE, 4-WIRENON-FUSED DISCONNECT600V, 400A, NEMA 3RNET GENERATOR OUTPUT METER (NGOM)CIRCUIT BREAKERNZMN3-400VE-NACHP SWGR150KW, 480V, 3-PHASE, 3-WIRECHPResoution No. 10930
EXHIBIT A Page 96
FILENAME:PLOT DATE:PLOT TIME:10/17/20174:25:20 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017EG IS
T
ERED
P
ROFESSIONALENGINEERSTATEOFCALI
FOR
NI
AELECTRI
C
R
AL No. E18650Exp.12-31-18B
AMEHWYSAE
T
98-X-6010XXPLANTW IDE ELECTRICAL
DEM O LITION
SL GOODRICH98-X-6010_668876.dgnEM ERG ENCY PO W ER
SING LE LINE DIAG RAM VSVAASWTDW800/400800/400250/100250/100800/400100/100100/100TDATDV AND LOAD TRANSFERCONTROL LOGICSTART/STOPAND GENERATORATS STATUS/CONTROL(TYP) ATS STATUS
(TYP) ATS FORCE TFR
(TYP) ATS INHIBIT SIGNAL
(AM PS XDCR)
FROM M SG
(VOLTS XDCR)
FROM M SG
100/50100/25250/150M CC A1
TO EM E 151
M CC A2
TO EM E 152
M CC B1
TO EM E 251
M CC B2
TO EM E 252
PANEL LP-F
EM E 605
TO
LP-G
TO EM E 705
M CC H
TO EM E 805
M CC J1E
TO EM E 851
SPARE
M CC J2E
TO EM E 852 BUS EG 480V, 30, 4W 2000A 50000A RMS SYM BRACINGCONTROL SECTIONDISTRIBUTION SECTION1000:5GENERATOREMERGENCY / PEAK SHAVINGNATURAL GAS/PROPANEKW/ 560 KWEME 930PROPANE ENGINENATURAL GASCONTROL PANELEMERGENCY GENERATOR400A, 10 SECGROUNDING RESISTORNEUTRALJK LANDM ANA M ATHEW S
Resoution No. 10930
EXHIBIT A Page 97
328674M3AUXILIARY LOADS)(INDUCTION GENERATORENGINE BUILDINGSLUDGE GASMCC-D3333333TREATMENT)(SECONDARYAIRAERATIONMCC-F1TREATMENT)(SECONDARYAIRAERATIONMCC-F23BUILDINGSWITCHGEARMCC-HA
AS3GND BUSFOR KW RECORDERTERMINAL STRIP480-120V480-120V248V DC BUSTO DPCSCREENINGSINFLUENT/MCC-A1SCREENINGSINFLUENT/MCC-A2BIOFILTERSCLARIFIERSMCC-B1BIOFILTERSCLARIFIERSMCC-B2AREAUNIT 4MCC J1AREAUNIT 4MCC J2MCC-J1EMCC-J2EEG/CB-7FROM SWBDEG/CB-4FROM SWBDEG/CB-3FROM SWBDEG/CB-1FROM SWBDEG/CB-2FROM SWBDLOSS O F DC
BUILDINGLOCATED IN SWITCHGEARMAIN SWITCHGEAR "MSG"P.G. & E. METERING SECTIONP.G. & E. SECTIONSMCC B BUILDINGLOCATED INMCC A BUILDINGLOCATED INBUS EXTENSIONPROVISIONS FOR FUTUREMCC J BUILDINGLOCATED INBUILDINGSWITCHGEAR LOCATED INTO DPCALARM
CONTROL PW R
800 AT800 AF52-10400 AT800 AF52-91200 AT1600 AF52-81200 AT1600 AF52-7800 AT800 AF52-6400 AT800 AF52-1400 AT800 AF52-2300 AT800 AF52-3300 AT800 AF52-4800 AT800 AF52-5AASAASAASAASAASAASAASAASAASVVS300 AT800 AF52-G480V, 3PH, 4W, 3000A COPPER BUS480V, 3PH, 4W, 3000A COPPER BUS3000:53000:53000:53000AF3000AT52-MSECTIONINCOMING EME 151NEMA 1480V, 400A, 65 KAICENCLOSED BREAKERNEMA 3R480V-480Y/277V260KVANEMA 3R600V, 400A, 3-PHASE, 4-WIRENON-FUSED DISCONNECT600V, 400A, NEMA 3RNET GENERATOR OUTPUT METER (NGOM)CIRCUIT BREAKERNZMN3-400VE-NACHP SWGR150KW, 480V, 3-PHASE, 3-WIRECHPFILENAME:PLOT DATE:PLOT TIME:10/17/20174:24:48 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017EG IS
T
ERED
P
ROFESSIONALENGINEERSTATEOFCALI
FOR
NI
AELECTRI
C
R
AL No. E18650Exp.12-31-18B
AMEHWYSAE
T
98-E-6001XXELECTRICAL
PLANTW IDE ELECTRICAL
M AIN SING LE LINE DIAG RAM
SL GOODRICH98-E-6001_668876.dgnREVISED 98-E-6020SEE DWGTO 44-MSG-1CONDUCTORS FROM SOURCE TO LOAD.CONDUIT FROM EXISTING ATS LOCATION TO LOAD. REPLACE WITH NEW EXISTING ATS LOCATION. SEE 98-X-6001 FOR DEMOLITION REQUIREMENTS. EXTEND PROTECT AND REUSE EXISTING CONDUIT FROM "NORMAL" POWER SOURCE TO 1.NOTES:NOTE 1NOTE 1NOTE 1NOTE 1NOTE 1NOTE 1JK LANDM ANA M ATHEW S "MSG-T"PAD MOUNTED TRANSFORMERPONDEQUALIZATION14-MCC-01Resoution No. 10930
EXHIBIT A Page 98
FILENAME:PLOT DATE:PLOT TIME:10/17/20174:25:44 PMCH2M HILL 2015. ALL RIGHTS RESERVED.THIS DOCUM ENT, AND THE IDEAS AND DESIGNS INCORPORATED HEREIN, AS AN INSTRUM ENT OF PROFESSIONAL SERVICE, IS THE PROPERTY OFREUSE OF DOCUM ENTS:123456BCDVERIFY SCALEBAR IS ONE INCH ONORIGINAL DRAWING.1"0cPROJDATEDATENO.
DSGN DR
REVISION
CHK
APVDBY
APVDSHEETDWG ACH2M HILL AND IS NOT TO BE USED, IN W HOLE OR IN PART, FOR ANY OTHER PROJECT W ITHOUT THE W RITTEN AUTHORIZATION OF CH2M HILL.668876APPVD BY
FACILITY PRO JECT
W ATER RESOURCE RECOVERY NOT FOR CONSTRUCTIONPRELIMINARY60% DESIGNOCTOBER 2017EG IS
T
ERED
P
ROFESSIONALENGINEERSTATEOFCALI
FOR
NI
AELECTRI
C
R
AL No. E18650Exp.12-31-18B
AMEHWYSAE
T
XXELECTRICAL
PLANTW IDE ELECTRICAL
SL GOODRICH98-E-6011_668876.dgnJK LANDM ANA M ATHEW S DISTRIBUTION SYSTEMPG&E OVERHEAD 12KV PG&E REVENUE METER SWITCHGEAR98-MSG-01SAM15098-DP-01EQUIPMENTPG&E OWNED98-T-013PH, 4 WIRE208Y/120V,12KV-45KVAMSG-T60HZ3PH, 4 W,480/277V,12KV-1500KVAMSG(EXIST)N.C.44-MSG-01CURRENT RATING (12KV NOMINAL VOLTAGE)15KV, 1200 AMPS, 3PH, 3W, 25KA SYMMETRICAL CURRENT RATING (12KV NOMINAL VOLTAGE)15KV, 1200 AMPS, 3PH, 3W, 25KA SYMMETRICAL 44-TIEGENBKR1G44-GEN-012500 KW53-T-0153-T-023PH, 4W, 60HZ480/277V,12KV-500KVA73-T-0173-T-023PH, 4W, 60HZ480/277V,12KV-500KVA40-T-0140-T-0253-SWBD-0153-SWBD-0240-SWBD-0140-SWBD-0273-MCC-0173-MCC-02SIZE BY PG&EPG&E CABLE RISER 98-E-6011OVERALL SING LE LINE DIAG RAM
3PH, 4W, 60HZ480/277V,12KV-1000KVA3PH, 4W, 60HZ480/277V,12KV-1000KVA(12KV NOMINAL VOLTAGE)SYMMETRICAL CURRENT RATING 15KV, 1200 AMPS, 3PH, 3W, 25KA BUS ABUS B98-E-6018DWG98-E-6019DWG98-E-6020DWG98-E-6021DWG98-E-6012DWG98-E-6015DWG98-E-6001DWGN.C.10-T-013PH, 4W, 60HZ480/277V,12KV-300KVA10-SWBD-0198-E-6018DWGN.O.525252525252525252SPACESPAREN.O.N.O.3PH, 4W, 60HZ480/277V,12KV-1000KVA3PH, 4W, 60HZ480/277V,12KV-1000KVAN.O.12KV, 3PH3125 KVACONTROLLER (RTAC)DEVICE AUTOMATIONResoution No. 10930
EXHIBIT A Page 99